17-R-33 - Agreement with Ford Engineering for Design, Bid and Construction Phase Engineering Services for the FM 1103 Water and Wastewater FacilitiesWHEREAS, the City staff of the City of Schertz (the "City ") has recommended that the
City enter into an agreement for design, bid, and construction phase engineering services for the
FM 1103 water and wastewater facilities relocation project in advance of the TxDOT FM 1103
road widening project; and
WHEREAS, the City Council has determined that it is in the best interest of the City to
contract with Ford Engineering, Inc., for the design, bid, and construction phase services as
described in the Project Agreement attached hereto. (the "Agreement ").
WHEREAS, the City Council authorizes expenditures with Ford Engineering, Inc., for
the FM 1103 Utility Relocation project in addition to the previously authorized not to exceed
amount of $162,000 for the 2016 -2017 Fiscal Year (for a new total not to exceed amount of
$200,013).
BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF SCHERTZ, TEXAS
THAT:
Section 1. The City Council hereby authorizes the City Manager to execute and
deliver the Agreement with Ford Engineering, Inc., in substantially the form set forth on
Attachment 1.
Section 2. The recitals contained in the preamble hereof are hereby found to be true,
and such recitals are hereby made a part of this Resolution for all purposes and are adopted as a
part of the judgment and findings of the City Council.
Section 3. All resolutions, or parts thereof, which are in conflict or inconsistent with
any provision of this Resolution are hereby repealed to the extent of such conflict, and the
provisions of this Resolution shall be and remain controlling as to the matters resolved herein.
Section 4. This Resolution shall be construed and enforced in accordance with the
laws of the State of Texas and the United States of America.
Section 5. If any provision of this Resolution or the application thereof to any person
or circumstance shall be held to be invalid, the remainder of this Resolution and the application
of such provision to other persons and circumstances shall nevertheless be valid, and the City
Council hereby declares that this Resolution would have been enacted without such invalid
provision.
Section 6. It is officially found, determined, and declared that the meeting at which
this Resolution is adopted was open to the public and public notice of the time, place, and subject
matter of the public business to be considered at such meeting, including this Resolution, was
given, all as required by Chapter 551, Texas Government Code, as amended.
Section 7. This Resolution shall be in force and effect from and after its final
passage, and it is so resolved.
PASSED AND ADOPTED, this 23rd day of May, 2017.
CITY OF Z, TEXAS
i e R. Carpenter, Mayor
ATTEST:
(fa Dennis, Ci ecretary
(CITY SEAL)
ATTACHMENT 1
,.o
I_m
This Agreement is entered into in the City of Schertz, Texas, between the City of Schertz, a
Texas municipal corporation, hereinafter called "CITY" and/or "OWNER ", and Ford
Engineering, Inc. hereinafter called "CONSULTANT ".
Engineer(s), duly licensed, and practicing under the laws of the State of Texas, hereinafter called
"CONSULTANT ", this Agreement being executed by City pursuant to appropriate action by the
City Council of CITY and by CONSULTANT, for engineering services hereinafter set forth in
connection with the above designated Project for CITY.
ARTICLE 1
DEFINITIONS
ARTICLE 2
SCOPE OF SERVICES
ARTICLE 3
COMPENSATION FOR SERVICES
ARTICLE 4
METHOD OF PAYMENT
ARTICLE 5
TIME, SCHEDULE, AND PERIOD OF SERVICE
ARTICLE 6
COORDINATION WITH CITY
ARTICLE 7
REVISIONS TO DRAWINGS AND SPECIFICATIONS
ARTICLE 8
OWNERSHIP OF DOCUMENTS
ARTICLE 9
TERMINATION AND /OR SUPENSION OF WORK
ARTICLE 10
CONSULTANT'S WARRANTY
ARTICLE 11
ASSIGNMENT OR TRANSFER OF INTEREST
ARTICLE 12
INSURANCE REQUIREMENTS
ARTICLE 13
INDEMNIFICATION
ARTICLE 14
CLAIMS AND DISPUTES
ARTICLE 15
SEVERABILITY
ARTICLE 16
ESTIMATES OF COST
ARTICLE 17
INTEREST IN CITY CONTRACTS PROHIBITED
ARTICLE 18
CONFLICTS OF INTEREST DISCLOSURE
ARTICLE 19
STANDARD OF CARE
ARTICLE 20
RIGHT OF REVIEW AND AUDIT
ARTICLE 21
ENTIRE AGREEMENTS
ARTICLE 22
VENUE
ARTICLE 23
NOTICES
ARTICLE 24
INDEPENDENT CONTRACTOR
ARTICLE 25
CAPTIONS
ATTACHMENT 1
PROJECT SCOPE OF SERVICES
ATTACHMENT 2
PROJECT DESIGN PHASES COST
ATTACHMENT 3
BILLING RATE SCHEDULE
ATTACHMENT 4
ADDITIONAL PROJECTS AND /OR EXPANDED SCOPE
OF SERVICES
FM 1103 Utility Relocation Project Page 1
ARTICLE l: DEFINITIONS
AS USED IN THIS AGREEMENT, THE FOLLOWING TERMS SHALL HAVE MEANINGS
AS SET OUT BELOW:
Agreement means this Master Agreement between CITY and CONSULTANT that
establishes the terms and conditions for all Projects to be carried out under this
Agreement.
Application for Compensation means the form CONSULTANT uses to make a request
to be paid for completed services.
Application for Payment means the form CONSTRUCTION CONTRACTOR uses to
make a request to be paid for completed work.
Certificate for Payment means the form CONSULTANT uses to make
recommendations on CONSTRUCTION CONTRACTOR'S Application for Payment.
CITY means the City of Schertz, Texas.
Claim means a demand or assertion by one of the parties seeking, as a matter of right,
adjustment, or interpretation of the terms of this Agreement, payment of money,
extension of time, or other relief with respect to the terms of this Agreement. The term
"claim" also includes other disputes and matters in question between the OWNER and
CONSULTANT arising out of or relating to this Agreement.
Compensation means amounts paid by CITY to CONSULTANT for completed services
under this Agreement.
CONSTRUCTION CONTRACTOR means the firm hired by CITY to construct the
Proj ect.
Construction Contract Documents means the contract between the CITY and the firm
contracted by CITY to construct the Project and all documents therein.
CONSULTANT means the entity named on the cover page of this Agreement and its
officers, partners, employees, agents, and representatives, and all its subconsultants, if
any, and all other persons or entities for which CONSULTANT is legally responsible.
ENGINEER means CITY's City Engineer.
Final Compensation means the final amounts paid by CITY to CONSULTANT for
completed services under this Agreement.
Final Payment means the final amounts paid by CITY to CONSTRUCTION
CONTRACTOR for completed work under the construction contract.
FM 1103 Utility Relocation Project Page 2
Opinion of Probable Construction Cost means CONSULTANT'S estimate of probable
construction cost for a Project based on its experience and qualifications as a practitioner
of its profession and the current costs in the local area.
OWNER means the City of Schertz, Texas.
Payment means amount paid by CITY to CONSTRUCTION CONTRACTOR for work
performed under the Construction Contract Documents.
Plans and Specifications means the construction documents.
Project means the capital improvement /construction development undertaking of CITY
for which CONSULTANT'S services, as stated in the Scope of Services, and to be
provided pursuant to this Agreement.
Proposal means CONSULTANT'S proposal to provide services for the Project.
Schedule of Values means the fees allocated to services, reimbursable and /or various
portions of the services or Work, prepared in such form, and supported by such data to
substantiate its accuracy as OWNER may require.
Scope of Services means the services described in Article 4, Scope of Services.
Services means professional services performed by CONSULTANT.
Total Compensation means the amount paid to CONSULTANT under Article 2,
Compensation for Basic Services, of this Agreement.
Work means the labor and materials required to complete a Project by
CONSTRUCTION CONTRACTOR in accordance with the Construction Contract
Documents.
ARTICLE 2: SCOPE OF SERVICES
2.1 CONSULTANT shall not commence work until being thoroughly briefed on the scope of
the Project and being notified in writing to proceed. The scope of the Project and
CONSULTANT'S Services required shall be reduced by CONSULTANT to a written
summary of the scope meeting. That Scope of Services and associated cost, once
approved by CITY, will be included as a part of this Agreement as Attachments 1 and 2
herein. Should the scope subsequently change, either CONSULTANT or CITY may
request a review of the anticipated services, with an appropriate adjustment in
compensation.
2.2 Communications by and with CONSULTANT'S subconsultants shall be through
CONSULTANT. Communications by and with subcontractors and material suppliers shall
be through CONSTRUCTION CONTRACTOR.
FM 1103 Utility Relocation Project Page 3
2.3 CONSULTANT, in consideration for the Compensation herein provided, shall render the
professional Services described in this Section that are necessary for the development of
the Project, including plans and specifications, construction management services, any
special and general conditions, and instructions to bidders as acceptable to the Engineer,
or his or her duly authorized representative.
2.4 CONSULTANT shall complete a Project in accordance with the following phases and
CONSULTANT'S Scope of Services attached and incorporated herein as Attachments I
and 2.
2.4.1 PROJECT DESIGN PHASES
2.4.2 60% Design Phase
2.4.3 90% Design Phase
2.4.4 Bid Phase
2.4.5 Construction Services including Closeout Phases
2.5 Upon acceptance and approval of the plans, reports or other deliverables required for a
Phase of work, as set forth in the Scope of Services, Engineer shall authorize
CONSULTANT, in writing, to proceed with the next phase of Work.
2.6 During Design Phases CONSULTANT shall:
2.6.1 Coordinate and meet with City staff and Project stakeholders as appropriate
throughout the Project. Assist staff at meetings with stakeholders, workshops,
and presentations to advisory commissions and City Council.
2.6.2 Provide the necessary field survey services to determine the existing field
conditions, including all utilities and surface features to the maximum extent
possible.
2.6.3 CONSULTANT shall make every effort to minimize utility adjustments, where
possible.
2.6.4 In the event electrical, communication, gas or other facilities are encountered,
CONSULTANT shall identify and incorporate those facilities at the completion of
each Project Phase in order to determine the magnitude of any potential
adjustment.
2.6.5 Perform the necessary testing to determine the existing site conditions and proper
design for construction and methods of any necessary demolition.
2.6.6 Follow and comply with the requirements for the Design Phases listed in this
Agreement, CITY'S Unified Development Code, if applicable, and CITY'S
Design Guidance Manual, both of which are incorporated by reference herein.
2.6.7 In case of conflicts, follow and comply with the most stringent requirements for
the Design Phases.
FM 1103 Utility Relocation Project Page 4
2.6.8 Prepare documents for, and coordinate with other utilities and associated local,
state, and federal agencies (including TCEQ, EPA, TxDOT, ACOE, etc.) as
required for the approval of all necessary permits (determined during scoping for
each individual project).
2.6.9 Provide detailed plans and specifications for the Project at appropriate progress
intervals in requested formats (may include hard copy, .pdf, and .dwg).
2.6. 10 Provide Opinion of Probably Construction Cost.
2.7 During Bid Phase CONSULTANT shall:
2.7.1 Provide unit price bid quantities in City bid form format for use in bid documents.
2.7.2 Provide bid sets of contract, technical specifications, plans, and any other
necessary documents in hard copy and digital format.
2.7.3 Attend pre -bid conference and prepare responses to questions and addenda as
necessary.
2.7.4 Research qualifications and references of apparent low bidder(s) and provide a
letter of recommendation for contract award.
2.8 During Construction Phase:
2.8.1 CONSULTANT shall monitor construction schedule.
2.8.2 CONSULTANT will make a minimum of two visits per month to the Project Site
at intervals appropriate to the Phases to (1) become generally familiar with and to
keep CITY informed about the progress and quality of the portion of the Work
completed, and (2) endeavor to guard CITY against defects in Work. However,
CONSULTANT will not be required to make exhaustive or continuous on -site
inspections to check the quality or quantity of the Work.
2.8.3 CONSULTANT will neither have control over or charge of, nor be responsible
for, the construction means, methods, techniques, sequences or procedures, or for
the safety precautions and programs in connection with the Work since these are
solely CONSTRUCTION CONTRACTOR'S rights and responsibilities under the
Contract Documents. CONSULTANT'S efforts will be directed toward providing
for CITY a greater degree of confidence that the completed Work will generally
conform to the Contract Documents.
2.8.4 CONSULTANT will not be responsible for CONSTRUCTION
CONTRACTOR'S failure to perform the Work in accordance with the
requirements of the Contract Documents. CONSULTANT will not have control
over or charge of and will not be responsible for acts or omissions of
CONSTRUCTION CONTRACTOR, subcontractors, or their agents or
employees, or any other persons or entities performing portions of the Work.
FM 1103 Utility Relocation Project Page 5
2.8.5 CONSULTANT and CITY have authority to reject Work that does not conform to
the Contract Documents. Whenever CONSULTANT or CITY considers it
necessary or advisable, either CITY or CONSULTANT may require inspection or
testing of the Work whether or not such Work is fabricated, installed or
completed. However, neither this authority of CONSULTANT or CITY, nor a
decision made by either, in good faith, to require or not require an inspection shall
give rise to a duty or responsibility of CONSULTANT or CITY to
CONSTRUCTION CONTRACTOR, subcontractors, material and equipment
suppliers, agents or employees, or other persons or entities performing portions of
the Work.
2.8.6 CONSULTANT will review and approve or take other appropriate action upon
CONSTRUCTION CONTRACTOR'S submittals such as Shop Drawings,
Product Data and Samples, but only for the limited purpose of checking for
conformance with information given and the design concept expressed in the
Contract Documents. CONSULTANT will respond to submittals such as Shop
Drawings, Product Data, and Samples pursuant to the procedures set forth in the
Project specifications. Review of such submittals is not conducted for the purpose
of determining the accuracy and completeness of equipment or systems, all of
which remain the responsibility of CONSTRUCTION CONTRACTOR as
required by the Contract Documents. CONSULTANT'S review of
CONSTRUCTION CONTRACTOR'S submittals shall not relieve
CONSTRUCTION CONTRACTOR of its obligations. CONSULTANT'S review
shall not constitute approval of safety precautions or any construction means,
methods, techniques, sequences or procedures unless otherwise specifically stated
by CONSULTANT. CONSULTANT'S approval of a specific item shall not
indicate approval of an assembly of which the item is a component.
2.8.7 CONSULTANT will, within three work days after receipt of CONSTRUCTION
CONTRACTOR'S Application for Payment review the Application for Payment
and either issue to OWNER and /or the affected utility a Certificate for Payment
for such amount as CONSULTANT determines is properly due, or notify
OWNER, any affected utility, and CONSTRUCTION CONTRACTOR in writing
of CONSULTANT'S reasons for withholding recommendation of approval in
whole or in part.
2.8.8 CONSULTANT'S issuance of a Certificate for Payment will constitute a
representation by CONSULTANT to OWNER, based on CONSULTANT'S
evaluation of the Work and the data comprising the Application for Payment, that
the Work has progressed to the point indicated and that, to the best of
CONSULTANT'S knowledge, information and belief, the quality of the work is
in accordance with the design agreement documents or Construction Contract
Documents. The foregoing representations are subject to an evaluation of the
Work for conformance with the design agreement documents, to results of
subsequent tests and inspections, to correction of minor deviations from the
design agreement documents prior to completion, and to any specific
qualifications expressed by CONSULTANT. The issuance of a Certificate for
FM 1103 Utility Relocation Project Page 6
Payment based on the CONSTRUCTION CONTRACTOR'S Application for
Payment will further constitute a representation that CONSTRUCTION
CONTRACTOR is entitled to payment in accordance with the Schedule of
Values. The issuance of Certificate for Payment will not be a representation that
CONSULTANT has (1) made exhaustive or continuous on -site inspections to
check the quality or quantity of the Work, (2) reviewed construction means,
methods, techniques, sequences or procedures, (3) reviewed copies of requisitions
received from Subcontractors and material suppliers and other data requested by
OWNER to substantiate Construction Contractor's right to payment, or (4) made
any examination to ascertain how or for what purpose CONSTRUCTION
CONTRACTOR has used money previously paid on account of the Application
for Payment sum.
2.8.9 CONSULTANT may recommend withholding an approval for Payment in whole
or in part, to the extent reasonably necessary to protect OWNER if, in
CONSULTANT'S opinion, the representations to OWNER required by Section
4.13 cannot be made. If CONSULTANT is unable to recommend approval of
payment in the amount of the Application, CONSULTANT will notify OWNER
and CONSTRUCTION CONTRACTOR as provided in Section 4.12. If OWNER
and CONSULTANT cannot agree on a revised amount, CONSULTANT will
promptly issue a Certificate for Payment for the amount for which
CONSULTANT is able to make such representations to OWNER.
CONSULTANT may also recommend withholding a Payment, because of
subsequently discovered evidence, may modify the whole or a part of a Certificate
for Payment to such extent as may be necessary, in CONSULTANT'S opinion, to
protect OWNER and the affected utility from loss for which CONSTRUCTION
CONTRACTOR is responsible, including loss resulting from acts and omissions
described below:
2.8.9.1 defective Work not remedied;
2.8.9.2 third parry claims filed or reasonable evidence indicating probable
filing of such claims for which CONSTRUCTION CONTRACTOR is
responsible hereunder unless security acceptable to OWNER and the
affected utility is provided by CONSTRUCTION CONTRACTOR;
2.8.9.3 failure of CONSTRUCTION CONTRACTOR to make payments
properly to the subcontractors and/or material providers;
2.8.9.4 reasonable evidence that the Work cannot be completed for the unpaid
balance of the agreement sum and CONSTRUCTION CONTRACTOR
has failed to provide OWNER and the affected utility adequate
assurance of its continued performance within a reasonable time after
demand;
2.8.9.5 damage to OWNER or another contractor;
FM 1103 Utility Relocation Project Page 7
2.8.9.6 reasonable evidence that the Work will not be completed within the
agreement time, and that the unpaid balance would not be adequate to
cover actual or liquidated damages for the anticipated delay; or
2.8.9.7 persistent failure by CONSTRUCTION CONTRACTOR to carry out
the Work in accordance with the Construction Contract Documents.
2.8. 10 When the above reasons for withholding payment are removed, payment will be
made for amounts previously withheld. OWNER shall not be deemed in default
by CONSULTANT by reason of withholding payment as provided herein.
2.8.11 CONSULTANT will prepare Change Orders and Field Work Directives, and,
with concurrence of OWNER, OWNER'S designated representative will have
authority to order minor changes in the Work not involving an adjustment in the
Total Compensation or an extension of the time for construction. Such changes
shall be effected by written order, which CONSTRUCTION CONTRACTOR
shall carry out promptly and record on the as -built plan.
2.8.12 Upon written request of CITY or CONSTRUCTION CONTRACTOR,
CONSULTANT will issue its interpretation of the requirements of the Plans and
Specifications. CONSULTANT'S response to such requests will be made in
writing within any agreed time limits or otherwise with reasonable promptness. If
no agreement is made concerning the time within which interpretations required
by CONSULTANT shall be furnished in compliance with Article IV, then delay
shall not be recognized on account of failure by CONSULTANT to furnish such
interpretations until 15 days after written request is made for CONSULTANT'S
interpretation.
2.8.13 Interpretations of CONSULTANT will be consistent with the intent of and
reasonably inferable from the Construction Contract Documents and will be in
writing or in the form of drawings.
2.8.14 CONSULTANT will advise and consult with CITY. CITY'S instructions to
CONSTRUCTION CONTRACTOR may be issued through CONSULTANT, but
CITY reserves the right to issue instructions directly to CONSTRUCTION
CONTRACTOR through inspectors or other designated CITY representatives.
2.8.15 CONSULTANT and CITY will conduct observations to determine the date of
substantial completion of the Work. CONSULTANT shall provide to CITY a
written recommendation of consideration of substantial completion of the Project.
2.8.16 CONSULTANT and CITY will conduct observations to determine the date of
final completion. CONSULTANT will receive and forward to CITY, for CITY'S
review and records, written warranties and related documents required by the
Construction Contract Documents and assembled by CONSTRUCTION
CONTRACTOR, and will issue a final Approval for Payment upon compliance
with the requirements of the Construction Contract Documents. Such final
Approval will be accompanied by a signed and sealed statement from the
FM 1103 Utility Relocation Project Page 8
CONSULTANT'S Engineer of Record that certifies to CITY that the project was
constructed in accordance with the approved plans and specifications.
2.8.17 CONSULTANT shall prepare record drawings from information submitted by
CONSTRUCTION CONTRACTOR and from CONSULTANT'S own
observations in accordance with City standards. CONSULTANT shall provide
record drawings in hard copy, .pdf, and .dwg formats to CITY.
T" SIMKO] 1111
3.1 Basic Services
3.1.1 Compensation for all Services included in this Agreement will be on a time and
expense not -to- exceed basis in accordance with the negotiated, approved schedule
of billing rates as set forth in Attachment 3. Not -to- exceed compensation
amounts, to the extent they have been negotiated shall be reflected in Attachment
3. A Proposal including a not -to- exceed cost will be provided by
CONSULTANT along with a Scope of Services for each Project (Attachments 1
and 2). The amount to be paid to CONSULTANT, including authorized
adjustments, is the total amount payable by OWNER to CONSULTANT for
performance of the Services for the Project under this Agreement. It is agreed
and understood that such amount will constitute full compensation to
CONSULTANT for Services included in the Scope of Services and shall meet all
requirements of CITY'S design guidelines applicable to the Project. Unless and
until CITY makes further appropriations for any Services not included in the
Scope of Services of this Agreement, the obligation of CITY to CONSULTANT
for Compensation in connection with this Agreement cannot and will not exceed
the sum described in this Section without further amendment to this Agreement.
3.1.2 No billing rate changes from those approved as Attachment 3 of this Agreement
shall be made during the term of this Agreement without the prior written
approval of CITY.
3.1.3 CONSULTANT shall submit monthly invoices to CITY describing the Services
performed the preceding month. CONSULTANT'S invoices shall include the
name of the person who performed the Service, a brief description of the Service
performed and the Phase of the Project to which the Service relates, the date(s)
the Service was performed, the number of hours spent on all Services billed on an
hourly basis, and a description of any subconsultant fees and/or reimbursable
expenditures.
3.1.4 CITY shall reimburse CONSULTANT only for those costs or expenses
specifically approved in this Agreement, or specifically approved in advance by
CITY. Unless otherwise approved, such costs shall be limited and include
nothing more than the following costs incurred by CONSULTANT:
3.1.4.1 Approved reproduction charges,
FM 1103 Utility Relocation Project Page 9
3.1.4.2 Actual costs of subconsultant(s) for performance of any of the Services
that CONSULTANT agrees to provide pursuant to this Agreement,
which have been approved in advance by CITY and awarded in
accordance with this Agreement.
3.1.4.3 Actual costs and /or other costs and /or payments specifically authorized
in advance by the CITY in writing and incurred by CONSULTANT in
the performance of this Agreement.
3.1.5 CONSULTANT shall complete the Project in accordance with the following
phases. For the purpose of establishing portions of compensation for separate
phases, more particularly described in the Scope of Services, Attachment 2 shall
apply.
30% Design Phase
60% Design Phase
90% Design Phase
Bid Phase
Construction Phase Services including Close Out
3.1.6 CONSULTANT shall, within 10 days following receipt of Compensation from
OWNER, pay all bills for Services performed and furnished hereunder by
subconsultant(s) of CONSULTANT in connection with the Project and the
performance of services and shall, if requested, provide OWNER with evidence
of such payment. CONSULTANT'S failure to make payments within such time
shall constitute a material breach of this Agreement unless CONSULTANT is
able to demonstrate to OWNER bona fide disputes associated with the Services of
the unpaid subconsultant and its services. CONSULTANT shall include a
provision in each of its sub agreements imposing the same payment obligations on
its subconsultants as are applicable to CONSULTANT hereunder, and if OWNER
so requests, shall provide evidence of such payments by CONSULTANT to
OWNER. If CONSULTANT has failed to make payment promptly to the
subconsultant for undisputed Services for which OWNER has made payment to
CONSULTANT, OWNER shall be entitled to withhold future payment to
CONSULTANT to the extent remaining unpaid by CONSULTANT necessary to
protect OWNER.
3.1.7 CONSULTANT warrants that title to all deliverables produced in the
performance of Services covered by an Application for Compensation will pass to
OWNER no later than the time of payment. CONSULTANT further warrants that
upon submittal of an Application for Compensation, all Services for which
Applications for Compensation have been previously issued and payments
received from OWNER shall, to the best of CONSULTANT'S knowledge,
information and belief be free and clear of liens, claims, security interests or
encumbrance in favor of CONSULTANT, or other persons or entities under
contract with CONSULTANT making a claim by reason of having provided labor
or services relating to CONSULTANT'S Services. CONSULTANT SHALL
FM 1103 Utility Relocation Project Page 10
INDEMNIFY AND HOLD OWNER HARMLESS FROM ANY LIENS,
CLAIMS, SECURITY INTEREST OR ENCUMBRANCES FILED BY
ANYONE CLAIMING BY, THROUGH OR UNDER THE ITEMS COVERED
BY PAYMENTS MADE BY OWNER TO CONSULTANT.
3.2 Additional Services
3.2.1 CONSULTANT shall not receive any compensation for additional Services
without prior written authorization of CITY. Compensation for duly authorized
additional Services shall be paid in accordance with the approved schedule of
billing rates as set forth in Attachment 3.
3.2.2 Examples of additional Services (not all inclusive)
3.2.2.1 Assistance to CITY as an expert witness in any litigation with third
parties arising from the development of construction of a Project
including the preparation of engineering data and reports.
3.2.2.2 Preparation of plats and field notes for acquisition of property.
3.2.2.3 Preparation of applications and supporting documents for governmental
grants, loans, or advances in connection with a Project; preparation of
review of environmental assessment and impact statements; review and
evaluation of the effect on the design requirements of a Project of any
such statements and documents prepared by others; and assistance in
obtaining approval of authorities having jurisdiction over the
anticipated environmental impact of a Project.
3.2.2.4 Making revisions in drawings, specifications, or other documents when
such revisions are inconsistent with written approvals or instructions
previously given, are required by the enactment or revision of codes,
laws, or regulations subsequent to the preparation of such documents or
are due to other causes not solely within the control of
CONSULTANT.
3.2.2.5 Making revisions to drawings or specifications occasioned by
acceptance of substitutions proposed by CONSTRUCTION
CONTRACTOR; and Services after the award of each contract in
evaluating and determining the acceptability of an unreasonable or
excessive number of substitutions proposed by CONSTRUCTION
CONTRACTOR.
3.2.2.6 Preparing drawings, specifications, and supporting data and providing
other Services in connection with change order requests to the extent
that the adjustment in the basic compensation resulting from the
adjusted construction cost is not commensurate with the Services
required of CONSULTANT, provided such change order requests are
required by causes not solely within the control of CONSULTANT; or
FM 1103 Utility Relocation Project Page 11
in connection with change orders requiring significant engineering
effort to compute and document the Work effort reflected by the
Change Order.
3.2.2.7 Investigations, surveys, valuations, inventories, or detailed appraisals of
facilities, construction and /or services not required by Project scope.
3.2.2.8 Investigations, surveys, audit, or inventories required in connection
with construction performed by CITY.
3.2.2.9 Additional Services during construction made necessary by:
3.2.2.9.1 Work damaged by fire or other cause during construction.
3.2.2.9.2 A significant amount of defective or neglected work of
CONSTRUCTION CONTRACTOR.
3.2.2.9.3 Failure of performance of CONSTRUCTION
CONTRACTOR.
3.2.2.9.4 Acceleration of the progress schedule required by CITY
involving Services beyond normal working hours.
3.2.2.9.5 Default by CONSTRUCTION CONTRACTOR.
3.2.2.10 Providing extensive assistance in the use of any equipment or system
such as initial start-up or testing, adjusting and balancing, preparation
of operation and maintenance manuals, training personnel for operation
and maintenance, and consultation during operation.
3.2.2.11 Providing Services relative to future facilities, systems, and equipment
which are not intended to be constructed during the Construction Phase.
3.2.2.12 Services after completion of the Construction Phase, such as
inspections during any guarantee period and reporting observed
deficiencies under guarantee called for in any contract for a Project.
3.2.2.13 Providing Services of geotechnical engineering firm to perform test
borings and other soil or foundation investigations and related analysis
not included in original Scope of Services for a Project.
3.2.2.14 Additional copies of Construction Contract Documents, review
documents, bidding documents, reports, and or drawings over the
number specified in the original Scope of Services for a Project.
3.2.2.15 Preparation of all documents dealing with 404 permits and railroad
agreements.
FM 1103 Utility Relocation Project Page 12
3.2.2.16 Providing photographs, renderings, or models for CITY use.
3.2.2.17 Providing aerial mapping Services.
3.2.2.18 Providing consulting engineering Services not related to a particular
design or construction Project.
3.3 All Applications for Compensation shall be submitted through Engineer's office.
ARTICLE 4: METHOD OF PAYMENT
4.1 Compensation may be made to CONSULTANT as appropriately indicated on monthly
Applications for Compensation prepared based on hourly rates, not to exceed amounts
estimated for each phase, as described in Article 2 and Attachments 1 and 2 hereof.
4.2 Project Close Out and Final Payment —
4.2.1 CONSULTANT shall not be entitled to final payment unless and until it submits
to OWNER its affidavit that the invoices for services, and other liabilities
connected with the services for which OWNER, or OWNER'S property, might be
responsible have been fully paid or otherwise satisfied or will be paid from final
payment; releases and waivers of liens from all CONSULTANT'S subconsultants
and of any and all other parties required by OWNER that are either unconditional
or conditional on receipt of final payment; certificates of insurance showing
continuation of required insurance coverage; such other documents as OWNER
may request; and consent of surety to final payment.
4.2.2 Final Compensation — The final compensation to be made by CITY to
CONSULTANT will be payable upon submission of the "Record Drawings ".
CONSULTANT agrees to submit "Record Drawings: in print media, electronic
format (.pdf and .dwg formats) and final billing within 45 days of final acceptance
of construction. Additionally, CONSULTANT agrees to submit a statement of
release with the final billing notifying CITY that there is no further compensation
owed to CONSULTANT by CITY beyond the final bill. Final billing shall
indicate "Final Bill — no additional compensation is due to CONSULTANT ".
4.3 OWNER may withhold compensation to such extent as may be necessary, in OWNER'S
opinion, to protect OWNER from damage or loss for which CONSULTANT is
responsible, because of,
4.3.1 delays in the performance of CONSULTANT'S services;
4.3.2 third party claims filed or reasonable evidence indicating probable filing of such
claims unless security acceptable to OWNER is provided by CONSULTANT;
4.3.3 failure of CONSULTANT to make payments properly to subconsultants or
vendors for labor, materials or equipment;
FM 1103 Utility Relocation Project Page 13
4.3.4 reasonable evidence that CONSULTANT'S work cannot be completed for the
amount unpaid under this Agreement;
4.3.5 damage to OWNER or CONSTRUCTION CONTRACTOR; or
4.3.6 persistent failure by CONSULTANT to carry out the performance of its Services
in accordance with this Agreement.
4.4 When the above reasons for withholding are removed or remedied by CONSULTANT,
compensation of the amount withheld will be made within a reasonable time. OWNER
shall not be deemed in default by reason of withholding compensation as provided for in
this Article.
4.5 In the event of any dispute(s) between the parties regarding the amount properly payable
for any Phase or as final Compensation, or regarding any amount that may be withheld by
OWNER, CONSULTANT shall be required to make a claim pursuant to and in
accordance with the terms of this Agreement and follow the procedures provided herein
for the resolution of such dispute. In the event CONSULTANT does not initiate and
follow the claims procedures provided in this Agreement in a timely manner and as
required by the terms thereof, any such claim shall be waived.
4.6 OWNER shall make final compensation for all sums due CONSULTANT not more than
30 days after CONSULTANT'S final Application for Compensation.
4.7 Acceptance of final compensation by CONSULTANT shall constitute a waiver of claims
except those previously made in writing and identified by CONSULTANT as unsettled at
the time of final Application for Compensation.
4.8 CONSULTANT agrees to maintain adequate books, payrolls and records satisfactory to
OWNER and all applicable utility providers in connection with any and all Services
performed hereunder. CONSULTANT agrees to retain all such books, payrolls and
records (including data stored in computer) for a period of not less than four years after
completion of Work. At all reasonable times, OWNER and all applicable utility providers
and their duly authorized representatives shall have access to all personnel of
CONSULTANT and all such books, payrolls and records, and shall have the right to audit
same.
►/ 1 1 ► 1 �[�71Z�1 10 01:1X/ [N'�I
5.1 Prior to commencement, CONSULTANT shall provide CITY with a schedule of Project
Design Phases, Attachment 2.
5.2 Time is of the essence of this Agreement. CONSULTANT shall perform and complete its
obligations for the various Phases of a Project under Section 4, Scope of Services, of this
Agreement in a prompt and continuous manner so as to not delay the development of the
design Services and so as to not delay the construction of the work for the Project in
accordance with the schedules approved by CITY with CONSTRUCTION
CONTRACTOR. Upon review of phase Services, if corrections, modifications,
FM 1103 Utility Relocation Project Page 14
alterations, or additions are required of CONSULTANT, these items shall be completed
by CONSULTANT before that Phase is approved.
5.3 CONSULTANT shall not proceed with the next appropriate Phase of Services without
written authorization from the Engineer. CITY may elect to discontinue
CONSULTANT'S Services at the end of any Phase for any reason. Notwithstanding any
other provisions of this Agreement, if circumstance dictates, the Engineer may make
adjustments to the scope of CONSULTANT'S obligations at any time to achieve the
required design.
5.4 CONSULTANT shall not be liable or responsible for any delays due to strikes, riots, acts
of God, national emergency, acts of the public enemy, governmental restrictions, laws or
regulations, or any other causes beyond CONSULTANT'S reasonable control. Within 21
days from the occurrence of any event for which time for performance by
CONSULTANT will be significantly extended under this provision, CONSULTANT
shall give written notice thereof to CITY stating the reason for such extension and the
actual or estimated time thereof. If CITY determines that CONSULTANT is responsible
for the need for extended time, CITY shall have the right to make a Claim as provided in
this Agreement.
5.5 Term of Agreement shall be as follows:
5.5.1 This Agreement shall become effective upon the date below and shall remain in
effect until satisfactory completion of the Project unless terminated as provided
for in this Agreement.
ARTICLE 6: COORDINATION WITH CITY
6.1 CONSULTANT shall hold periodic conferences with the Engineer or his or her
representatives to the end that the Project as developed shall have the full benefit of
CITY'S experience and knowledge of existing needs and facilities, and be consistent with
its current policies and standards. To assist CONSULTANT in this coordination, CITY
shall make available for CONSULTANT'S use in planning and designing the Project all
existing plans, maps, statistics, computations and other data in its possession relative to
existing facilities and to this particular Project, at no cost to CONSULTANT. However,
any and all such information shall remain the property of CITY and shall be returned by
CONSULTANT upon termination or completion of the Project or if instructed to do so by
the Engineer.
6.2 The Engineer will act on behalf of CITY with respect to the Services to be performed
under this Agreement. The Engineer shall have complete authority to transmit
instructions, receive information, interpret and define CITY'S policies and decisions with
respect to materials, equipment, elements and systems pertinent to CONSULTANT'S
services.
6.3 CITY will give prompt written notice to CONSULTANT whenever CITY observes or
otherwise become aware of any defect in CONSULTANT'S Services, in the work of
FM 1103 Utility Relocation Project Page 1S
CONSTRUCTION CONTRACTOR, or any development that affects the scope or timing
of CONSULTANT'S Services.
6.4 All appraisals, notices, and permits shall be furnished by CONSULTANT under the Scope
of Services unless otherwise assigned to CITY in the Scope of Services, Approvals and
permits assigned to CITY shall be obtained from all governmental authorities having
jurisdiction over the Project and such approvals and consents from others as may be
necessary for the completion of the Project. CONSULTANT will provide CITY
reasonable assistance in connection with such approvals and permits such as the
furnishing of data compiled by CONSULTANT pursuant to other provisions of this
Agreement, but CONSULTANT shall not be obligated to develop additional data, prepare
extensive reports or appear at hearings or the like unless compensated therefore under
other provisions of this Agreement.
7.1 CONSULTANT shall make without expense to CITY such revisions to the drawings,
reports or other documents as may be required to meet the needs of CITY which are
within the Scope of Services, but after the approval of drawings, reports or other
documents and specifications by CITY, any revisions, additions, or other modifications
made at CITY'S request which involve extra services and expenses to CONSULTANT
shall be at additional compensation to CONSULTANT for such additional Services and
expenses in accordance with Article 3 herein.
ARTICLE 8: OWNERSHIP OF DOCUMENTS
8.1 All previously owned documents, including the original drawings, estimates,
specifications, and all other documents and data by CONSULTANT, will remain the
property of CONSULTANT as instruments of service. However, CONSULTANT
understands and agrees that CITY shall have free access to all such information with the
right to make and retain copies of previously owned drawings, estimates, specifications
and all other documents and data. Any reuse without specific written verification or
adaptation by CONSULTANT will be at CITY'S sole risk and without liability or legal
exposure to CONSULTANT.
8.2 All completed documents submitted by CONSULTANT for final approval or issuance of
a permit shall bear the seal with signature and date adjacent thereto of a registered
professional engineer licensed to practice in the State of Texas.
8.3 CONSULTANT acknowledges and agrees that upon payment, CITY shall own
exclusively any and all information in whatsoever form and character produced and /or
maintained in accordance with, pursuant to, or as a result of this Agreement and shall be
used as CITY desires and documents, including the original drawings, estimates,
specifications and all other documents and data shall be delivered to CITY at no
additional cost to CITY upon request or termination or completion of this Agreement
without restriction on future use. However, any reuse without specific written verification
FM 1103 Utility Relocation Project Page 16
or adaptation by CONSULTANT will be at CITY'S sole risk and without liability to
CONSULTANT.
8.4 CONSULTANT agrees and covenants to protect any and all proprietary rights of CITY in
any materials provided to CONSULTANT. Such protection of proprietary rights by
CONSULTANT shall include, but not be limited to, the inclusion in any copy intended for
publication of copyright mark reserving all rights to CITY. Additionally, any materials
provided to CONSULTANT by CITY shall not be released to any third parry without the
written consent of CITY and shall be returned intact to CITY upon termination or
completion of this Agreement or if instructed to do so by the Engineer.
8.6 CONSULTANT may make copies of any and all documents and items for its files.
CONSULTANT shall have no liability for changes made to or use of the drawings,
specifications and other documents by other engineers, or other persons, subsequent to the
completion of the Project. CONSULTANT shall appropriately mark all changes or
modifications on all drawings, specifications and other documents by other engineers or
other persons, including electronic copies, subsequent to the completion of the Project.
8.7 Copies of documents that may be relied upon by CITY are limited to the printed copies
(also known as hard copies) and .pdf- format electronic versions that are sealed and signed
by CONSULTANT. Files in editable electronic media format of text, data, graphics, or
other types (such as .dwg) that are furnished by CONSULTANT to CITY are only for
convenience of CITY or any utility. Any conclusion or information obtained or derived
from such electronic files will be at the user's sole risk. Any reuse without specific written
verification or adaptation by CONSULTANT will be at CITY'S sole risk and without
liability to CONSULTANT.
FM 1103 Utility Relocation Project Page 17
8.8 Notwithstanding anything to the contrary contained herein, all previously owned
intellectual property of CONSULTANT, unless expressly purchased by CITY, including
but not limited to any computer software (object code and source code), tools, systems,
equipment or other information used by CONSULTANT or its suppliers in the course of
delivering the Services hereunder, and any know -how, methodologies, or processes used
by CONSULTANT to provide the services or protect deliverables to CITY, including
without limitation, all copyrights, trademarks, patents, trade secrets, and any other
proprietary rights inherent therein and appurtenant thereto shall remain the sole and
exclusive property of CONSULTANT or its suppliers.
9.1 Right of Either Party to Terminate for Default
9.1.1 This Agreement may be terminated by either parry for substantial failure by the
other parry to perform (through no fault of the terminating parry) in accordance
with the terms of this Agreement and a failure to cure as provided in this Article
9.
9.1.2 The party not in default must issue a signed, written notice of termination (citing
this paragraph) to the other party declaring the other party to be in default and
stating the reason(s) why they are in default. Upon receipt of such written notice
of default, the party in receipt shall have a period of ten days to cure any failure to
perform under this Agreement. Upon the completion of such 10 -day period
commencing upon receipt of notice of termination, if such party has not cured any
failure to perform, such termination shall become effective without further written
notice.
9.2 Right of CITY to Terminate
9.2.1 CITY reserves the right to terminate this Agreement for reasons other than
substantial failure by CONSULTANT to perform by issuing a signed, written
notice of termination (citing this paragraph) which shall take effect on the
twentieth day following receipt of said notice or upon the scheduled completion
date of the performance Phase in which CONSULTANT is then currently
working, whichever effective termination date occurs first.
9.3 Right of CITY to Suspend Giving Rise to Right of CONSULTANT to Terminate
9.3.1 CITY reserves the right to suspend this Agreement at the end of any Phase for the
convenience of CITY by issuing a signed, written notice of suspension (citing this
paragraph) which shall outline the reasons for the suspension and the expected
duration of the suspension, but such expected duration shall in no way guarantee
what the total number of days of suspension will occur. Such suspension shall
take effect immediately upon receipt of said notice of suspension by
CONSULTANT.
FM 1103 Utility Relocation Project Page 18
9.3.1.1 CONSULTANT is hereby given the right to terminate this Agreement
in the event such suspension extends for a period in excess of 120 days.
CONSULTANT may exercise this right to terminate by issuing a
signed, written notice of termination (citing this paragraph) to CITY
after the expiration of 120 days from the effective date of the
suspension. Termination (under this paragraph) shall become effective
immediately upon receipt of said written notice by CITY.
9.4 Procedures CONSULTANT Shall Follow upon Receipt of Notice of Termination
9.4.1 Upon receipt of a notice of termination and prior to the effective date of
termination, unless the notice otherwise directs or CONSULTANT immediately
takes action to cure a failure to perform under the cure period set out in this
Article. CONSULTANT shall immediately begin the phase -out and the
discontinuance of all services in connection with the performance of this
Agreement and shall proceed to promptly cancel all existing orders and contracts
insofar as such orders and contracts are chargeable to this Agreement. Within 30
days after receipt of such notice of termination (unless CONSULTANT has
successfully cured a failure to perform) CONSULTANT shall submit a statement
showing in detail the Services performed under this Agreement prior to the
effective date of termination. CITY shall have the option to grant an extension to
the time period for submittal of such statement.
9.4.2 Copies of all completed or partially completed specifications and all
reproductions of all completed or partially completed designs, plans and
attachments prepared under this Agreement prior to the effective date of
termination shall be delivered to CITY, in the form requested by CITY as a
precondition to final payment. These documents shall be subject to the restrictions
and conditions set forth in Article IX above.
9.4.3 Upon the above conditions being met, CITY shall promptly pay CONSULTANT
that proportion of the prescribed Compensation which the Services actually
performed under this Agreement bear to the total Services called for under this
Agreement, less previous payments of the Compensation.
9.4.4 CITY, as a public entity, has a duty to document the expenditure of public funds.
CONSULTANT acknowledges this duty on the part of CITY. To this end,
CONSULTANT understands that failure of CONSULTANT to comply with the
submittal of the statement and documents as required above shall constitute a
waiver by CONSULTANT of any and all rights or claims for compensation for
services performed under this Agreement by CONSULTANT.
9.4.5 Failure of CONSULTANT to comply with the submittal of the statement and
documents as required above shall constitute a waiver by CONSULTANT of any
and all rights or claims to collect monies that CONSULTANT may otherwise be
entitled to for services performed under this Agreement.
FM 1103 Utility Relocation Project Page 19
9.5 Procedures CONSULTANT Shall Follow upon Receipt of Notice of Suspension
9.5.1 Upon receipt of written notice of suspension, which date shall also be the
effective date of the suspension, CONSULTANT shall, unless the notice
otherwise directs, immediately begin to phase -out and discontinue all services in
connection with the performance of this Agreement and shall proceed to promptly
suspend all existing orders and contracts insofar as such orders and contracts are
chargeable to this Agreement.
9.5.2 CONSULTANT shall prepare a statement showing in detail the Services
performed under this Agreement prior to the effective date of suspension.
9.5.3 Copies of all completed or partially completed designs, plans, and specifications
prepared under this Agreement prior to the effective date of suspension shall be
prepared for possible delivery to CITY but shall be retained by CONSULTANT
until such time as CONSULTANT may exercise the right to terminate.
9.5.4 In the event that CONSULTANT exercises the right to terminate 120 days after
the effective suspension date, within 30 days after receipt by CITY of
CONSULTANT'S notice of termination, CONSULTANT shall promptly cancel
all existing orders and contracts insofar as such orders and contracts are
chargeable to this Agreement and shall submit the above referenced statement
showing in detail the services performed under this Agreement prior to the
effective date of suspension.
9.5.5 Any documents prepared in association with this Agreement shall be delivered to
CITY as a precondition to final payment.
9.5.6 Upon the above conditions being met, CITY shall pay CONSULTANT that
proportion of the prescribed Compensation which the Services actually performed
under this Agreement bear to the total Services called for under this Agreement,
less previous payments of Compensation.
9.5.7 CITY, as a public entity, has a duty to document the expenditure of public funds.
CONSULTANT acknowledges this duty on the part of CITY. To this end,
CONSULTANT understands that failure of Consultant to substantially comply
with the submittal of the statements and documents as required herein shall
constitute a waiver by CONSULTANT of any portion of the Compensation for
which CONSULTANT did not supply such necessary statements and/or
documents.
ARTICLE 10: CONSULTANT'S WARRANTY
10.1 CONSULTANT warrants that it has not employed or retained any company or person
other than a bona fide employee working solely for CONSULTANT to solicit or secure
this Agreement, and that it has not, for the purpose of soliciting or securing this
Agreement, paid or agreed to pay any company or person, commission, percentage,
brokerage fee, gift, or any other consideration, contingent upon or resulting from the
FM 1103 Utility Relocation Project Page 20
award or making of this Agreement. For breach of this warranty, CITY shall have the
right to terminate this Agreement under the provisions of Article 9 above.
11.1 CONSULTANT shall not assignor transfer its interest in this Agreement without the prior
written consent of CITY.
12.1 Prior to the commencement of any Services under this Agreement, CONSULTANT shall
furnish copies of all required endorsements and an original completed Certificate(s) of
Insurance to CITY'S Engineering Department, which shall be clearly identified with the
name of the Project in the Description of Operations block of the Certificate. The original
Certificate(s) shall be completed by an agent and signed by a person authorized by that
insurer to bind coverage on its behalf. CITY will not accept Memorandum of Insurance or
Binders as proof of insurance. The original certificate(s) or form must have the agent's
original signature, including the signer's company affiliation, title and phone number, and
be mailed, with copies of all applicable endorsements, directly from the insurer's
authorized representative to CITY. CITY shall have no duty to pay or perform under this
Agreement until such certificate and endorsements have been received and approved by
CITY'S Engineering Department. No officer or employee other than CITY'S Risk
Manager shall have authority to waive this requirement.
12.2 CITY reserves the right to review the insurance requirements of this Article during the
effective period of this contract and any extension or renewal hereof and to request
modification of insurance coverage's and their limits when deemed necessary and prudent
by CITY'S Risk Manager based upon changes in statutory law, court decisions, or
circumstances surrounding this contract. In no instance will CITY allow modification
whereupon CITY may incur increased risk.
12.3 CONSULTANT'S financial integrity is of interest to CITY. Therefore, subject to
CONSULTANT'S right to maintain reasonable deductibles in such amounts as are
approved by CITY, CONSULTANT shall obtain and maintain in full force and effect for
the duration of this Agreement, and any extension hereof, at CONSULTANT'S sole
expense, insurance coverage written on an occurrence or claims made basis, as
appropriate, by companies authorized and approved to do business in the State of Texas
and with an A.M. Best's rating of no less than A- (VII), in the following types and for an
amount not less than the amount listed:
FM 1103 Utility Relocation Project Page 21
INSURANCE REQUIREMENTS
Worker's Compensation*
Employer's Liability
Commercial General (Public) Liability
insurance to include coverage for the
following:
a. Premises Operations
b. Independent Contractors **
c. Products /Completed Operations
d. Personal Injury
e. Contractual Liability
Statutory
$1,000,000 /$1,000,000 /$1,000,000
For Bodily Injury and Property Damage of
$1,000,000 per occurrence.
$2,000,000 General Aggregate, or its equivalent
in Umbrella or Excess Liability Coverage
Business Automobile Liability Combined Single Limit for Bodily Injury and
a. Owned /Leased Vehicles property Damage of $1,000,000 per occurrence
b. Non -owned Vehicles
c. Hired Vehicles
Professional Liability (Claims Made Form) $1,000,000 per claim to pay on behalf of the
insured all sums, which the insured shall
become legally obligated to pay as damages to
the extent caused by any negligent act, error, or
omission in the performance of professional
services.
*Alternate Plans must be approved by CITY'S Risk Manager
* *If applicable
12.4 CITY may request and without expense to CITY, to inspect copies of the policies,
declarations page and all endorsements thereto as they apply to the limits required by
CITY, and may request the deletion, revision, or modification of particular policy terms,
conditions, limitations or exclusions (except where policy provisions are established by
law or regulation binding upon either of the parties hereto or the underwriter of any such
policies). CONSULTANT shall attempt to comply with any such requests, subject to the
policy terms and conditions, and shall submit a copy of the replacement certificate of
insurance to CITY at the address provided below within 10 days of the requested change,
in the event the respective insurance companies approve the requested change(s).
CONSULTANT shall pay any costs incurred resulting from said changes.
City of Schertz
Attn: City Engineer
10 Commercial Place
Schertz, TX 78154
FM 1103 Utility Relocation Project Page 22
12.5 CONSULTANT agrees that with respect to the above required insurance, all insurance
policies are to contain or be endorsed to contain the following required provisions:
12.5.1 Name CITY and its officers, officials, employees, and elected representatives as
additional insured's by endorsement, as respects operations and activities of, or on
behalf of, the named insured performed under contract with CITY, with the
exception of the workers' compensation and professional liability policies;
12.5.2 Provide for an endorsement that the "other insurance" clause shall not apply to the
CITY where CITY is an additional insured shown on the policy if such
endorsement is permitted by law and regulations;
12.5.3 Workers' compensation and employers' liability policies will provide a waiver of
subrogation in favor of CITY; and
12.5.4 Provide 30 calendar days advance written notice directly to CITY of any
suspension, cancellation or non - renewal or material change in coverage, and not
less than 10 calendar days advance written notice for nonpayment of premium.
12.6 Within five calendar days after a suspension, cancellation or non - renewal of coverage,
CONSULTANT shall provide a replacement Certificate of Insurance and applicable
endorsements to CITY. CITY shall have the option to suspend CONSULTANT'S
performance should there be a lapse in coverage at any time during this Agreement.
Failure to provide and to maintain the required insurance shall constitute a material breach
of this Agreement.
12.7 If CONSULTANT fails to maintain the aforementioned insurance, or fails to secure and
maintain the aforementioned endorsements, CITY may obtain such insurance, and deduct
and retain the amount of the premiums for such insurance from any sums due under the
agreement; however, procuring of said insurance by CITY is an alternative to other
remedies CITY may have and is not the exclusive remedy for failure of CONSULTANT
to maintain said insurance or secure such endorsement. In addition to any other remedies
CITY may have upon CONSULTANT'S failure to provide and maintain any insurance or
policy endorsements to the extent and within the time herein required, CITY shall have
the right to order CONSULTANT to stop performing services hereunder and /or withhold
any payment(s) which become due to CONSULTANT hereunder until CONSULTANT
demonstrates compliance with the requirements hereof.
12.8 Nothing herein contained shall be construed as limiting in any way the extent to which
CONSULTANT may be held responsible for payments of damages to persons or property
resulting from CONSULTANT'S or its subconsultant's performance of the Services
covered under this Agreement.
12.9 It is agreed that CONSULTANT'S insurance shall be deemed primary with respect to any
insurance or self insurance carried by CITY for liability arising out of operations under
this Agreement.
FM 1103 Utility Relocation Project Page 23
12. 10 It is understood and agreed that the insurance required is in addition to and separate from
any other obligation contained in this Agreement as respects additional insured's.
El 'AV to a on RAMMI 1 1
13.2 CONSULTANT shall advise CITY in writing within 24 hours of any claim or demand
against CITY or CONSULTANT, known to CONSULTANT, related to or arising out of
CONSULTANT'S activities under this Agreement.
13.3 The provisions of Article 13 are solely for the benefit of the parties hereto and not
intended to create or grant any rights, contractual or otherwise, to any other person or
entity.
13.4 Acceptance of the final plans by CITY shall not constitute nor be deemed a release of the
responsibility and liability of CONSULTANT, its employees, associates, agents or
subcontractors for the accuracy and competency of their designs, work drawings, Plans
and Specifications or other documents and Work; nor shall such acceptance be deemed an
assumption of responsibility or liability by CITY for any defect in the designs, work
FM 1103 Utility Relocation Project Page 24
drawings, Plans and Specifications or other documents and Work prepared by
CONSULTANT, its employees, subconsultants, and agents.
ARTICLE 14: CLAIMS AND DISPUTES
14.1 Definition. A Claim is a demand or assertion by one of the parties seeking, as a matter of
right, adjustment or interpretation of this Agreement's terms, payment of money, and
extension of time or other relief with respect to the terms of this Agreement. The term
"Claim" also includes other disputes and matters in question between OWNER and
CONSULTANT arising out of or relating to this Agreement. Claims must be initiated by
written notice. Every Claim of CONSULTANT, whether for additional Compensation,
additional time, or other relief, shall be signed and sworn to by an authorized corporate
officer (if not a corporation, then an official of the company authorized to bind
CONSULTANT by signature) of CONSULTANT, verifying the truth and accuracy of the
Claim. The responsibility to substantiate Claims shall rest with the party making the
Claim.
14.2 Time Limit on Claims. Claims by CONSULTANT or by OWNER must be initiated
within 30 calendar days after occurrence of the event giving rise to such Claim. Claims by
CONSULTANT must be initiated by written notice to OWNER. Claims by the OWNER
must be initiated by written notice to CONSULTANT.
14.3 Continuing Contract Performance. Pending final resolution of a Claim except as otherwise
agreed in writing, CONSULTANT shall proceed diligently with performance of this
Agreement and OWNER shall continue to make payments in accordance with this
Agreement.
14.4 Claims for Additional Time. If CONSULTANT wishes to make Claim for an increase in
the time for performance, written notice as provided in this Article 14 shall be given.
CONSULTANT'S Claim shall include an estimate of probable effect of delay on progress
of the Work. In the case of a continuing delay only one Claim is necessary.
14.5 Claims for Consequential Damages. Except as otherwise provided in this Agreement, in
calculating the amount of any Claim or any measure of damages for breach of contract
(such provision to survive any termination following such breach), the following
standards will apply both to claims by CONSULTANT and to claims by OWNER:
14.5.1 No consequential damages will be allowed.
14.5.2 Damages are limited to extra costs specifically shown to have been directly
caused by a proven wrong for which the other party is claimed to be responsible.
14.5.3 No profit will be allowed on any damage claim.
14.6 No Waiver of Governmental Immunity. NOTHING IN THIS AGREEMENT SHALL
BE CONSTRUED TO WAIVE OWNER'S GOVERNMENTAL IMMUNITY
FROM LAWSUIT, WHICH IMMUNITY IS EXPRESSLY RETAINED TO THE
FM 1103 Utility Relocation Project Page 25
EXTENT IT IS NOT CLEARLY AND UNAMBIGUOUSLY WAIVED BY STATE
LAW.
ARTICLE 15: SEVERABILITY
15.1 If for any reason, any one or more paragraphs of this Agreement are held invalid or
unenforceable, such invalidity or unenforceability shall not affect, impair or invalidate the
remaining paragraphs of this Agreement but shall be confined in its effect to the specific
section, sentences, clauses or parts of this Agreement held invalid or unenforceable, and
the invalidity or unenforceability of any section, sentence, clause or parts of this
Agreement in any one or more instance shall not affect or prejudice in any way the
validity of this Agreement in any other instance.
ARTICLE 16: ESTIMATES OF COST
16.1 Since CONSULTANT has no control over the cost of labor, materials, or equipment or
over CONSTRUCTION CONTRACTOR'S methods of determining prices, or over
competitive bidding or market conditions, CONSULTANT'S opinions of probable Project
Cost or Construction Cost provided for herein are to be made on the basis of
CONSULTANT'S experience and qualifications and represent CONSULTANT'S best
judgment as a design professional familiar with the construction industry but
CONSULTANT cannot and does not guarantee that bids or the construction cost will not
vary from opinions of probable Cost prepared by CONSULTANT.
ARTICLE 17: INTEREST IN CITY CONTRACTS PROHIBITED
17.1 No officer or employee of CITY shall have a financial interest, directly or indirectly, in
any contract with CITY, or shall be financially interested, directly or indirectly, in the sale
to CITY of any land, materials, supplies or service, except on behalf of CITY as an officer
or employee. This prohibition extends to other CITY boards and commissions, which are
more than purely advisory. The prohibition also applies to subcontracts on CITY projects.
17.2 CONSULTANT acknowledges that it is informed that the Charter of CITY prohibits a
CITY officer or employee, as those terms are defined in the Ethics Code, from having a
financial interest in any contract with CITY or any CITY agency.
17.3 CONSULTANT warrants and certifies, and this Agreement is made in reliance thereon,
that it, its officers, employees and agents are neither officers nor employees of CITY.
CONSULTANT further warrants and certifies that it has tendered to CITY a
Discretionary Contracts Disclosure Statement.
ARTICLE 18: CONFLICTS OF INTEREST DISCLOSURE
18.1 All consultants must disclose if it is associated in any manner with a CITY official or
employee in a business venture or business dealings. To be "associated" in a business
venture or business dealings includes being in a partnership or joint venture with the
officer or employee, having a contract with the officer or employee, being joint owners of
a business, owning at least 10% of the stock in a corporation in which a CITY officer or
FM 1103 Utility Relocation Project Page 26
employee also owns at least 10 %, or having an established business relationship as client
or customer.
19.1 Services provided by CONSULTANT under this Agreement will be performed in a
manner consistent with that degree of care and skill ordinarily exercised by members of
the same profession currently practicing under similar circumstances.
19.2 CONSULTANT shall be represented by a registered professional engineer licensed to
practice in the State of Texas at meetings of any official nature concerning the Project,
including but not limited to scope meetings, review meetings, pre -bid meetings, and
preconstruction meetings.
19.3 The Texas Board of Professional Engineers, 1917 IH -35 South, Austin, Texas 78741,
(512) 440 -7723 has jurisdiction over individuals licensed under Title 22 of the Texas
Administrative Code.
19.4 Acceptance of the final plans by CITY shall not constitute nor be deemed a release of the
responsibility and liability of CONSULTANT, its employees, associates, agents, or
subcontractors for the accuracy and competency of their designs, work drawings, Plans
and Specifications or other documents and Work; nor shall such acceptance be deemed an
assumption of responsibility or liability by CITY for any defect in the designs, work
drawings, Plans and Specifications or other documents and Work prepared by
CONSULTANT, its employees, subconsultants, and agents.
ARTICLE 20: RIGHT OF REVIEW AND AUDIT
20.1 CONSULTANT agrees that CITY may review any and all of the work performed by
CONSULTANT UNDER THIS Agreement. CITY is granted the right to audit, at
CITY'S election, all of CONSULTANT'S records and billings related to performance of
this Agreement. CONSULTANT agrees to retain such records for a minimum of four
years following completion of this Agreement. Any payment, settlement, satisfaction, or
release provided under this Agreement shall be subject to CITY'S rights as may be
disclosed by such audit.
ARTICLE 21: ENTIRE AGREEMENT
21.1 This Agreement, together with Attachments 1, 2, 3, and 4, represents the entire and
integrated agreement between CITY and CONSULTANT and supersedes all prior
negotiations, representations, or agreements, either oral or written. This Agreement may
be amended only by written instrument signed by both CITY and CONSULTANT.
ARTICLE 22: VENUE
22.1 The obligations of the parties to this Agreement shall be performable in the City of
Schertz or its Extra Territorial Jurisdiction, located in Bexar, Comal, and Guadalupe
FM 1103 Utility Relocation Project Page 27
Counties, Texas, and if legal action, such as civil litigation, is necessary in connection
therewith, exclusive venue shall lie in Guadalupe County, Texas.
23.1 Except as may be provided elsewhere herein, all notices, communications, and reports
required or permitted under this Contract shall be personally delivered or mailed to the
respective party by depositing the same in the United States Postal Service addressed to
the applicable address shown below, unless and until either party is otherwise notified in
writing by the other party of a change of such address. Mailed notices shall be deemed
communicated as of five calendar days of mailing. Notices provided via email shall be
deemed communicated as of the next business day after the notice is sent.
If intended for CITY, to:
If intended for CONSULTANT, to:
City of Schertz
Engineering Department
10 Commercial Place
Schertz, Texas 78154
The address listed on the first page of this
Agreement.
24.1 In performing services under this Agreement, the relationship between CITY and
CONSULTANT is that of independent contractor. By the execution of this Agreement,
CONSULTANT and CITY do not change the independent contractor status of
CONSULTANT. CONSULTANT shall exercise independent judgment in performing its
duties and obligations under this Agreement and is solely responsible for setting working
hours, scheduling or prioritizing the work flow and determining how the Services are to be
performed. No term or provision of this Agreement or act of CONSULTANT in the
performance of this Agreement shall be construed as making CONSULTANT the agent,
servant or employee of CITY, or as making CONSULTANT or any of its agents or
employees eligible for any fringe benefits, such as retirement, insurance and worker's
compensation, which CITY provides to or for its employees.
ARTICLE 25: CAPTIONS
25.1 The captions for the individual provisions of this Agreement are for informational
purposes only and shall not be construed to effect or modify the substance of the terms
and conditions of this Agreement to which any caption relates.
FM 1103 Utility Relocation Project Page 28
IN WITNESS WHEREOF, the parties to this Agreement hereby execute this Agreernent
effective as of _ 2017 . (the "Effective Bate "),
C'IT'E" OF SCHERTZ CONSULTANT
CITY NT ANAL ER.
Consultant Name
Mark_ B. Hill RE. - Principal
TITLE
FM 1103 Utility Relocation Project Page 29
ATTACHMENT 1
PROJECT SCOPE OF SERVICES
Project Design Description:
Consultant shall provide civil engineering professional consulting services to the City of Schertz
for the design, bid and construction services for the adjustments of the existing water mains and
sewer mains on FM 1103, from IH 35 north bound frontage road to the intersection of Chelsea
Rd, and at the intersections of Fortune Hill, Chelsea Rd, and Old Wiederstein Road. The design
of the adjustment to the existing water and sewer mains shall be in coordination with TxDOT' s
design of the reconstruction of FM 1103 and associated drainage improvements for that same
region.
Specific Scope of Services:
Consultant shall prepare a set of construction plans, specifications, and quantity estimates, for
review, approval, and construction with associated details for the replacement of existing water
mains for the limits of the project as described above.
The City will provide consultant with CAD base files of the TXDOT design, including the
existing topographic survey, the proposed road design, the proposed drainage layout files, and
the proposed right of way limits.
The City will provide five approximately eight (8) potholes on the existing water main on FM
1103 at locations identified by FEL
It is anticipated that the City of Schertz improvements will be constructed separately from and
prior to the TXDOT improvements, and FEI will provide a design for temporary erosion control
measures, temporary traffic control and project phase sequencing.
Consultant's design shall include the extension of a sanitary sewer at IH 35 north bound frontage
road, and approximately 15 locations of conflict with the existing main and the proposed road
and drainage improvements. The plans shall provide for the reconnections of all existing
services, trench restoration per the City of Schertz specifications, and tie -ins to existing mains.
Consultant shall provide an opinion on probable cost based on similar projects and best available
information.
The City will provide the front end documents for the bid documents and specifications.
Consultant shall provide the bid proposal documents and fill in the appropriate data for the bid
documents. The City will determine bid dates, City project numbers, and other project
identifying information as required.
TXDOT has provided the City with 60% design phase construction documents. It is anticipated
that FEI will provide submittals to the City of Schertz for 60% design phase and the 90% design
phase.
FM 1103 Utility Relocation Project Page 30
® The 60% submittal shall include an opinion of probable cost, and the plans developed to
at least 60% completion, showing alignments, fittings, services and limits of
construction of base bid and additive alternates. Plans will be 22 -inch by 34 -inch. The
submittal documents will be provided in digital format (PDF) to the City for review.
® The 90% submittal shall include an opinion of probable cost, construction plans
developed to at least 90% completion, and bid document complete with the exception
of pertinent dates and information to be provided by the City. The plans will
incorporate all City comments provided on the 60% submittal. Plans will be 22 -inch
by 34 -inch. The submittal documents will be provided in digital format (PDF) to the
City for review. Changes in design/scope requested by the City after this submittal
requiring additional construction plan sheets, changes in limits of work or alignment
of utility, will be considered additional service negotiated by change order.
® The 100% submittal or Bid Set shall include an opinion of probable cost, and the
construction plans and Bid Documents. The submittal documents will be provided in
digital format (PDF) to the City for review.
Consultant shall aid in the bidding process (answering contractor questions and issuing of
addendums as required). Consultant shall have a representative available for pre -bid and bid
opening meetings with the City of Schertz. Upon receipt of bid proposals, Consultant shall
provide a tabulation of bid, call three references of the apparent low bidder, provide the City with
a recommendation of award, and assist the City in providing copies of contract documents for
signatures by all parties.
Consultant shall have a representative available for pre - construction and monthly project
meetings during construction. Consultant and its team member shall provide eight (8) site visits
in order to observe general construction progress and determine compliance with the plans and
specifications. Consultant shall review up to eight (8) monthly and one final payment
applications by the contractor, and provide recommendations to the City for payment. If the
project duration requires more than eight monthly payment application reviews, the time
required of Consultant will be compensated at an hourly rate determined in Attachment 3 of this
agreement. Consultant and their team shall review contractor's submittals, respond to RFI's, and
issue change orders as required. Consultant and its team shall have representatives present at the
site for project walkthrough and prepare a punch list of corrections for final approval of the
project.
After construction has been completed and work approved by the City, Consultant shall
incorporate any changes made during construction, as indicated by the contractor on a marked up
set of plans, into a set of Project Record Drawings.
FM 1103 Utility Relocation Project Page 31
ATTACHMENT 2
PROSECT PHASE
ES 11NIIATED COST
TEVIE IN CALENDAR
DAYS
Prelim.inary Engineering Report
30,a.
�� Lesion
-
-
60% Design
S 15,608.00
30
90`'1/� Desiytt
$12,435.00
20
Bid Phase
$4,745
30
Construction Phase includinc,
5,??)0
___
Closeout
TOTAI. ESTIMATED COST
$38,013.00
(NOT -TO- EXCEED AMOUNT)
FM 1103 Utility Relocation Project Pa -e 3'2
ATTACHMENT 3
Discipline
Principal
Sr. Civil Enc ineer (PE)
EIT
Clerical Staff
Re�istered Professional Land
Surveyor (RPL S)
SuiA,eyr Technician
2-Person Survey Crew
3-Person StraNCY Crew
4 -flan Crem,
Hourly- late
$200,00
S 165.00
$95.00
$65.00
S 150,00
S85,00
1=15.00
1.65.00
S 135:00
FM l t03 Utility Relocation Pro ect Page 33
♦ U ` I%
To be completed as necessary.
CITY MANAGER
CONSULTANT
Consultant Name
TITLE
FM 1103 Utility Relocation Project Page 34