Loading...
23-R-115 On-Call SCADA System ServicesRESOLUTION NO. 23-R-115 A RESOLUTION BY THE CITY COUNCIL OF THE CITY OF SCHERTZ, TEXAS AUTHORIZING THE CITY MANAGER TO ENTER INTO AN CONTRACT FOR ON -CALL SCADA SYSTEM SERVICES AND OTHER MATTERS IN CONNECTION THEREWITH WHEREAS, the City of Schertz (the "City") has a need for SCADA system services for maintenance and emergencies; and WHEREAS, two bids were received through the sealed bidding process; and WHEREAS, City staff has determined that Prime Controls is qualified to provide such services for the City; and WHEREAS, the City Council has determined that it is in the best interest of the City to contract with Prime Controls pursuant to the recommendation of City staff. NOW THEREFORE, BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF SCHERTZ, TEXAS THAT: Section 1. The City Council hereby authorizes the City Manager to execute and deliver a contract with Prime Controls for on -call SCADA system services in substantially the form attached hereto as Exhibit "A" (On -Call SCADA Services Contract). Section 2. The recitals contained in the preamble hereof are hereby found to be true, and such recitals are hereby made a part of this Resolution for all purposes and are adopted as a part of the judgment and findings of the City Council. Section 3. All resolutions, or parts thereof, which are in conflict or inconsistent with any provision of this Resolution are hereby repealed to the extent of such conflict, and the provisions of this Resolution shall be and remain controlling as to the matters resolved herein. Section 4. This Resolution shall be construed and enforced in accordance with the laws of the State of Texas and the United States of America. Section 5. If any provision of this Resolution or the application thereof to any person or circumstance shall be held to be invalid, the remainder of this Resolution and the application of such provision to other persons and circumstances shall nevertheless be valid, and the City Council hereby declares that this Resolution would have been enacted without such invalid provision. Section 6. It is officially found, determined, and declared that the meeting at which this Resolution is adopted was open to the public and public notice of the time, place, and subject matter of the public business to be considered at such meeting, including this Resolution, was given, all as required by Chapter 551, Texas Goverment Code, as amended. Section 7. This Resolution shall be in force and effect from and after its final passage, and it is so resolved. PASSED AND ADOPTED, this [�t7 day of M+"t'f�,�'ib23. CITY OF SCl i TZ, TEXAS R Ap rez,ayor ATT Sheila Edmondson, City Secretary EXHIBIT "A" On -Call SCADA Services Contract CITY OF SCHERTZ SERVICE AGREEMENT THE STATE OF TEXAS § GUADALUPE COUNTY § This Service Agreement ("Agreement") is made and entered by and between the City of Schertz, Texas, (the "City") a Texas municipality, and Prime Controls, L.P. ("Contractor"). Section 1. Duration This Agreement shall become effective upon the date of the final signature affixed hereto and shall remain in effect through September 30, 2024, with the option to renew for two (2) additional terms of one (1) year each unless terminated as provided for in this Agreement. The renewals on this agreement shall not extend beyond September 30, 2026. Section 2. Scope of Work (A) Contractor shall perform the Work as more particularly described in the Scope of Work attached hereto as Exhibit "A". The work as described in the Scope of Work constitutes the "Project". (B) The Quality of Work provided under this Agreement shall be of the level of quality performed by Contractors regularly rendering this type of service. (C) The Contractor shall perform its Work for the Project in compliance with all statutory, regulatory and contractual requirements now or hereafter in effect as may be applicable to the rights and obligations set forth in the Agreement. (D) The Contractor may rely upon the accuracy of reports and surveys provided to it by the City except when defects should have been apparent to a reasonably competent Contractor or when it has actual notice of any defects in the reports and surveys. Section 3. Compensation (A) The Contractor shall be paid in full upon completion of the project or in the manner set forth in Exhibit "A" and as provided herein. (B) Billing Period Subject to Chapter 2251, Texas Government Code (the "Prompt Payment Act"), payment is due within thirty (30) days of the City's receipt of the Contractor's invoice. Interest on overdue payments shall be calculated in accordance with the Prompt Payment Act. (C) Reimbursable Expenses. Any and all reimbursable expenses related to the Project shall be included in the scope of Work (Exhibit A) and accounted for in the total contract amount, CITY OF SCHERTZ PAGE 1 Prime Controls, L.P. Service Agreement (D) Payments Subject to Future Appropriation. This Agreement shall not be construed as a commitment, issue, pledge or obligation of any specific taxes or tax revenues for payment to Contractor. (1) All payments or expenditures made by the City under this Agreement are subject to the City's appropriation of funds for such payments or expenditures to be paid in the budget year for which they are made. (2) The payments to be made to Contractor, or other expenditures under this Agreement, if paid, shall be made solely from annual appropriations of the City as may be legally set aside for the implementation of Article III, Section 52-a of the Texas Constitution or Chapter 380 of the Texas Local Government Code or any other economic development or financing program authorized by statute or home rule powers of the City under applicable Texas law, subject to any applicable limitations or procedural requirements. (3) In the event the City does not appropriate funds in any fiscal year for payments due or expenditures under this Agreement, the City shall not be liable to Contractor for such payments or expenditures unless and until appropriation of said funds is made; provided, however, that Contractor, in its sole discretion, shall have the right but not the obligation to terminate this Agreement and shall have no obligations under this Agreement for the year in respect to which said unappropriated funds relate. (4) To the extent there is a conflict of this Section and any other language or covenants in this Agreement, this Section 3 shall control. Section 4. Time of Completion The prompt completion of the Work under the Scope of Work relates is critical to the City. Unnecessary delays in providing Work under a Scope of Work shall be grounds for dismissal of the Contractor and termination of this Agreement without any or further liability to the City other than a prorated payment for necessary, timely, and conforming work done by Contractor prior to the time of termination. (A) Contract Times: Days N/A (B) Liquidated Damages Contractor and Owner recognize that time is of the essence as stated above and that Owner will suffer financial and other losses if the Work is not completed and Milestones not achieved within the times specified in the Scope of Work, plus any extensions thereof allowed in accordance with the Contract. The Contractor acknowledges and recognizes that the Owner is entitled to full and beneficial occupancy and use of the completed work following expiration of the Contract Time. The Contractor further acknowledges and agrees that, if the Contractor fails to substantially, or cause the Substantial Completion of any portion of the Work within the Contract time, the Owner will sustain actual damages as a result of such failure. The exact amount of such damages will be difficult to ascertain. Therefore, the Owner and Contractor agree that, if the Contractor shall neglect, fail, or refuse to achieve substantial completion of the Work by the Substantial Completion date, subject to proper extension granted by the Owner, then the Contractor agrees to pay the Owner the sum of Six hundred dollars ($600.00) per day for each day in which such Work is not completed, not as penalty, but as liquidated damages, for the damages CITY OF SCHERTZ PAGE 2 Prime Controls, L.P. Service Agreement ("Liquidated Damages") that would be suffered by Owner as a result of delay for each and every calendar day that the Contractor shall have failed to have completed the Work as required herein. The Liquidated Damages shall be in lieu of any and all other damages which may be incurred by Owner as a result of the failure of Contractor to complete within the Contract Time. Section 5. Insurance Before commencing work under this Agreement, Contractor shall obtain and maintain the liability insurance provided for below throughout the term of the Project plus an additional two years. Contractor shall provide evidence of such insurance to the City. Such documentation shall meet the requirements noted in Exhibit B. Contractor shall maintain the following limits and types of insurance: Workers Compensation Insurance: Contractor shall carry and maintain during the term of this Agreement, workers compensation and employers liability insurance meeting the requirements of the State of Texas on all the Contractor's employees carrying out the work involved in this contract. General Liability Insurance: Contractor shall carry and maintain during the term of this Agreement, general liability insurance on a per occurrence basis with limits of liability not less than $1,000,000 for each occurrence and for fire damage. For Bodily Injury and Property Damage, coverage shall be no less than $1,000,000. As a minimum, coverage for Premises, Operations, Products and Completed Operations shall be $2,000,000. This coverage shall protect the public or any person from injury or property damages sustained by reason of the Contractor or its employees carrying out the work involved in this Agreement. The general aggregate shall be no less than $2,000,000. Automobile Liability Insurance: Contractor shall carry and maintain during the term of this Agreement, automobile liability insurance with either a combined limit of at least $1,000,000 per occurrence for bodily injury and property damage or split limits of at least $1,000,000 for bodily injury per person per occurrence and $1,000,000 for property damage per occurrence. Coverage shall include all owned, hired, and non -owned motor vehicles used in the performance of this contract by the Contractor or its employees. Subcontractor: In the case of any work sublet, the Contractor shall require subcontractor and independent contractors working under the direction of either the Contractor or a subcontractor to carry and maintain the same workers compensation and liability insurance required of the Contractor. Qualifying Insurance: The insurance required by this Agreement shall be written by non -assessable insurance company licensed to do business in the State of Texas and currently rated "B+" or better by the A.M. Best Companies. All policies shall be written on a "per occurrence basis" and not a "claims made" form. Evidence of such insurance shall be attached as Exhibit "C". Failure of Certificate Holder to demand a certificate or other evidence of full compliance with these insurance requirements or failure of Certificate Holder to identify a deficiency from evidence that is CITY OF SCHERTZ PAGE 3 Prime Controls, L.P. Service Agreement provided will not be construed as a waiver of Insured's obligation to maintain such insurance. Section 6. Miscellaneous Provisions (A) Subletting. The Contractor shall not sublet or transfer any portion of the work under this Agreement or any Scope of Work issued pursuant to this Agreement unless specifically approved in writing by the City, which approval shall not be unreasonably withheld. Subcontractors shall comply with all provisions of this Agreement and the applicable Scope of Work. The approval or acquiescence of the City in the subletting of any work shall not relieve the Contractor of any responsibility for work done by such subcontractor. (B) Compliance with Laws. The Contractor shall comply with all federal, state and local laws, statutes, ordinances, rules and regulations, and the orders and decrees of any courts, administrative, or regulatory bodies in any matter affecting the performance of this Agreement, including, without limitation, worker's compensation laws, minimum and maximum salary and wage statutes and regulations, and licensing laws and regulations. When required, the Contractor shall furnish the City with satisfactory proof of compliance. (C) Independent Contractor. Contractor acknowledges that Contractor is an independent contractor of the City and is not an employee, agent, official or representative of the City. Contractor shall not represent, either expressly or through implication, that Contractor is an employee, agent, official or representative of the City. Income taxes, self-employment taxes, social security taxes and the like are the sole responsibility of the Contractor. (D) Non -Collusion. Contractor represents and warrants that Contractor has not given, made, promised or paid, nor offered to give, make, promise or pay any gift, bonus, commission, money or other consideration to any person as an inducement to or in order to obtain the work to be provided to the City under this Agreement. Contractor further agrees that Contractor shall not accept any gift, bonus, commission, money, or other consideration from any person (other than from the City pursuant to this Agreement) for any of the Work performed by Contractor under or related to this Agreement. If any such gift, bonus, commission, money, or other consideration is received by or offered to Contractor, Contractor shall immediately report that fact to the City and, at the sole option of the City, the City may elect to accept the consideration for itself or to take the value of such consideration as a credit against the compensation otherwise owing to Contractor under or pursuant to this Agreement. (E) Force Majeure. If the performance of any covenant or obligation to be performed hereunder by any party is delayed as a result of circumstances which are beyond the reasonable control of such party (which circumstances may include, without limitation, pending litigation, acts of God, war, acts of civil disobedience, fire or other casualty, shortage of materials, adverse weather conditions [such as, by way of illustration and not of limitation, severe rain storms or below freezing temperatures, or tornados] labor action, strikes or similar acts, moratoriums or regulations or actions by governmental authorities), the time for such performance shall be extended by the amount of time of such delay, but no longer than the amount of time reasonably occasioned by the delay. The party claiming delay of performance as a result of any of the foregoing force majeure events shall deliver written notice of the commencement of any such delay resulting from such force majeure event not later than seven (7) days after the claiming party becomes aware of the same, and if the claiming party fails to so notify the other party of the occurrence of a force majeure event causing such delay and the other party CITY OF SCHERTZ PAGE 4 Prime Controls, L.P. Service Agreement shall not otherwise be aware of such force majeure event, the claiming party shall not be entitled to avail itself of the provisions for the extension of performance contained in this subsection. (F) Conflict of Terms. Scope of work. - In the case of any conflicts between the terms of this Agreement within the Scope of Work, this Agreement shall govern. The Scope of Work is intended to detail the technical scope of Work, fee schedule, and contract time only and shall not dictate Agreement terms. Other Agreements between parties: In the case of any conflicts between the terms of this Agreement and wording contained within any other attachment, amendment, and agreement executed between the parties in conjunction with this Agreement, this Agreement shall govern. (G) Non -Boycott of Israel. Pursuant to Section 2270.002 of the Texas Government Code, Contractor certifies that either (i) it meets an exemption criterion under Section 2270.002; or (ii) it does not boycott Israel and will not boycott Israel during the term of the contract resulting from this solicitation. Contractor shall state any facts that make it exempt from the boycott certification as an attachment to this agreement. Relevant definitions from the bill: "Company" means a for -profit sole proprietorship, organization, association, corporation, partnership, joint venture, limited partnership, limited liability partnership, or limited liability company, including a wholly owned subsidiary, majority -owned subsidiary, parent company, or affiliate of those entities or business associations that exists to make a profit. "Boycott Israel" means refusing to deal with, terminating business activities with, or otherwise taking any action that is intended to penalize, inflict economic harm on, or limit commercial relations specifically with Israel, or with a person or entity doing business in Israel or in an Israeli -controlled territory, but does not include an action made for ordinary business purposes. (H) Non -Boycott of Energy. Pursuant to Texas Senate Bill 13 (2021), Contractor certifies that either (i) it does not boycott Israel and will not boycott energy companies; and (2) will not boycott energy companies during the term of the contract resulting from this solicitation. Contractor shall state any facts that make it exempt from the boycott certification as an attachment to this agreement. (I) Non -Boycott of Firearm Entity. Pursuant to Texas Senate Bill 19 (2021), Contractor certifies that it: (a) does not have a practice, policy, guidance, or directive that discriminates against a firearm entity or firearm trade association; and (b) will not discriminate during the term of the contract against a firearm entity or firearm trade association . (J) Access to Premises. Authorized representatives of the Contractor will be allowed access to the facilities on City premises at reasonable times to perform the obligations of the Contractor CITY OF SCHERTZ PAGE 5 Prime Controls, L.P. Service Agreement regarding such facilities. Contractor shall adhere to all City rules, regulations, and guidelines while on City property. It is expressly understood that the City may limit or restrict the right of access herein granted in any manner considered necessary (e.g., national security, public safety). (K) Interlocal Participation. The City may enter into Interlocal Cooperation Purchasing Agreements with other governmental entities or governmental cooperatives (hereafter collectively referred to as "Entity" or "Entities") to enhance the City's purchasing power. At the City's sole discretion and option, City may inform other Entities that they may acquire items listed in this IFB. Such acquisition(s) shall be at the prices stated herein, and shall be subject to bidder's acceptance. Entities desiring to acquire items listed in this IFB shall be listed on a rider attached hereto, if known at the time of issuance of the IFB. City may issue subsequent riders after contract award setting forth additional Entities desiring to utilize this bid. VENDOR shall sign and return any subsequently issued riders within ten calendar days of receipt. In no event shall City be considered a dealer, re -marketer, agent or other representative of Vendor or Entity. Further, City shall not be considered and is not an agent; partner or representative of the Entity making purchases hereunder, and shall not be obligated or liable for any such order. Entity purchase orders shall be submitted to Vendor by the Entity. City will not be liable or responsible for any obligations, including, but not limited to, payment, and for any item ordered by an entity other than City. Vendor authorizes City's use of Vendor's name, trademarks and Vendor provided materials in City's presentations and promotions regarding the availability of use of this contract. The City makes no representation or guarantee as to any minimum amount being purchased by City or Entities, or whether Entity will purchase utilizing City's contract. Section 7. Termination (A) This Agreement may be terminated: (1) By the mutual agreement and consent of both Contractor and City; (2) By either party, upon the failure of the other party to fulfill its obligations as set forth in either this Agreement or a Scope of Work issued under this Agreement; (3) By the City, immediately upon notice in writing to the Contractor, as consequence of the failure of Contractor to perform the Work contemplated by this Agreement in a timely or satisfactory manner; (4) By the City, at will and without cause upon not less than thirty (30) days written notice to the Contractor. (B) If the City terminates this Agreement pursuant to subsection 7(A)(2) or (3), above, the CITY OF SCHERTZ PAGE 6 Prime Controls, L.P. Service Agreement Contractor shall not be entitled to any fees or reimbursable expenses other than the fees and reimbursable expenses then due and payable as of the time of termination and only then for those Work that have been timely and adequately performed by the Contractor considering the actual costs incurred by the Contractor in performing work to date of termination, the value of the work that is nonetheless usable to the City, the cost to the City of employing another Contractor to complete the work required and the time required to do so, and other factors that affect the value to the City of the work performed at time of termination. In the event of termination not the fault of the Contractor, the Contractor shall be compensated for all basic, special, and additional Work actually performed prior to termination, together with any reimbursable expenses then due. Section 8. Indemnification CONTRACTOR AGREES TO INDEMNIFY AND HOLD THE CITY OF SCHERTZ, TEXAS AND ALL OF ITS PRESENT, FUTURE AND FORMER AGENTS, EMPLOYEES, OFFICIALS AND REPRESENTATIVES HARMLESS IN THEIR OFFICIAL, INDIVIDUAL AND REPRESENTATIVE CAPACITIES FROM ANY AND ALL CLAIMS, DEMANDS, CAUSES OF ACTION, JUDGMENTS, LIENS AND EXPENSES (INCLUDING ATTORNEY'S FEES, WHETHER CONTRACTUAL OR STATUTORY), COSTS AND DAMAGES (WHETHER COMMON LAW OR STATUTORY), COSTS AND DAMAGES (WHETHER COMMON LAW OR STATUTORY, AND WHETHER ACTUAL, PUNITIVE, CONSEQUENTIAL OR INCIDENTAL), OF ANY CONCEIVABLE CHARACTER, FOR INJURIES TO PERSONS (INCLUDING DEATH) OR TO PROPERTY (BOTH REAL AND PERSONAL) CREATED BY, ARISING FROM OR IN ANY MANNER RELATING TO THE WORK OR GOODS PERFORMED OR PROVIDED BY CONTRACTOR — EXPRESSLY INCLUDING THOSE ARISING THROUGH STRICT LIABILITY OR UNDER THE CONSTITUTIONS OF THE UNITED STATES. Section 9. Notices Any notice required or desired to be given from one party to the other party to this Agreement shall be in writing and shall be given and shall be deemed to have been served and received (whether actually received or not) if (i) delivered in person to the address set forth below; (ii) deposited in an official depository under the regular care and custody of the United States Postal Service located within the confines of the United States of America and sent by certified mail, return receipt requested, and addressed to such party at the address hereinafter specified; or (iii) delivered to such party by courier receipted delivery. Either party may designate another address within the confines of the continental United States of America for notice, but until written notice of such change is actually received by the other party, the last address of such party designated for notice shall remain such parry's address for notice. Section 10. No Assienment Neither party shall have the right to assign that parry's interest in this Agreement without the prior written consent of the other party. Section 11. Severability If any term or provision of this Agreement is held to be illegal, invalid or unenforceable, the legality, validity or enforceability of the remaining terms or provisions of this Agreement shall not be affected thereby, and in lieu of each such illegal, invalid or unenforceable term or provision, there shall be added automatically to this Agreement a legal, valid or enforceable term or provision as similar as possible to the term or provision declared illegal, invalid or unenforceable. CITY OF SCHERTZ PAGE 7 Prime Controls, L.P. Service Agreement Section 12. Waiver Either City or the Contractor shall have the right to waive any requirement contained in this Agreement that is intended for the waiving parry's benefit, but, except as otherwise provided herein, such waiver shall be effective only if in writing executed by the party for whose benefit such requirement is intended. No waiver of any breach or violation of any term of this Agreement shall be deemed or construed to constitute a waiver of any other breach or violation, whether concurrent or subsequent, and whether of the same or of a different type of breach or violation. Section 13. Governine Law; Venue This Agreement and all of the transactions contemplated herein shall be governed by and construed in accordance with the laws of the State of Texas. The provisions and obligations of this Agreement are performable in Guadalupe County, Texas such that exclusive venue for any action arising out of this Agreement shall be in Guadalupe County, Texas. Section 14. Paragraph Headings; Construction The paragraph headings contained in this Agreement are for convenience only and shall in no way enlarge or limit the scope or meaning of the various and several paragraphs hereof. Both parties have participated in the negotiation and preparation of this Agreement and this Agreement shall not be construed either more or less strongly against or for either party. Section 15. Bindine Effect Except as_ limited herein, the terms and provisions of this Agreement shall be binding upon and inure to the benefit of the parties hereto and their respective heirs, devisees, personal and legal representatives, successors and assigns. Section 16. Gender Within this Agreement, words of any gender shall be held and construed to include any other gender, and words in the singular number shall be held and construed to include the plural, unless the context otherwise requires. Section 17. Counterparts This Agreement may be executed in multiple counterparts, each of which shall be deemed an original, and all of which shall constitute but one and the same instrument. Section 18. Exhibits & Attachments All exhibits and attachments to this Agreement are incorporated herein by reference for all purposes wherever reference is made to the same. Section 19. Entire Agreement It is understood and agreed that this Agreement, which incorporates the original RFP, Contractor's Response to RFP, and Purchase Order(s) issued for payment contains the entire agreement between the parties and supersedes any and all prior agreements, arrangements or understandings between the parties relating to the subject matter. No oral understandings, statements, promises or inducements contrary to the terms of this Agreement exist. This Agreement cannot be changed or terminated orally. Order of Precedence. In the event of a conflict between the terms and conditions included in the body of this Agreement and the terms and conditions included in any of the incorporated CITY OF SCIIERTZ PAGE 8 Prime Controls, L.P. Service Agreement documents, the order of precedence shall be: (a)Agreement; (b) the attachments and/or exhibits to Agreement, (c)Contractor's Response to RFP, and (d) Purchase Order(s). Section 20. Relationship_ of Parties Nothing contained in this Agreement shall be deemed or construed by the parties hereto or by any third party to create the relationship of principal and agent or of partnership or of joint venture or of any association whatsoever between the parties, it being expressly understood and agreed that no provision contained in this Agreement nor any act or acts of the parties hereto shall be deemed to create any relationship between the parties other than the relationship of independent parties contracting with each other solely for the purpose of effecting the provisions of this Agreement. Section 21. Ri£ht To Audit City shall have the right to examine and audit the books and records of Contractor with regards to the work described in Exhibit A, or any subsequent changes, at any reasonable time. Such books and records will be maintained in accordance with generally accepted principles of accounting and will be adequate to enable determination of: (1) the substantiation and accuracy of any payments required to be made under this Agreement; and (2) compliance with the provisions of this Agreement. Section 22. Dispute Resolution In accordance with the provisions of Subchapter I, Chapter 271, TEx. LOCAL GOV'T CODE, the parties agree that, prior to instituting any lawsuit or other proceeding arising from a dispute under this agreement, the parties will first attempt to resolve the dispute by taking the following steps: (1) A written notice substantially describing the nature of the dispute shall be delivered by the dissatisfied party to the other parry, which notice shall request a written response to be delivered to the dissatisfied party not less than 5 days after receipt of the notice of dispute. (2) If the response does not reasonably resolve the dispute, in the opinion of the dissatisfied party, the dissatisfied party shall give notice to that effect to the other party whereupon each party shall appoint a person having authority over the activities of the respective parties who shall promptly meet, in person, in an effort to resolve the dispute. (3) If those persons cannot or do not resolve the dispute, then the parties shall each appoint a person from the highest tier of managerial responsibility within each respective party, who shall then promptly meet, in person, in an effort to resolve the dispute. Section 23. Disclosure of Business Relationships/Affiliations, Conflict of Interest Questionnaire Contractor represents that it is in compliance with the applicable filing and disclosure requirements of Chapter 176 of the Texas Local Government Code. Certificate of Interested Parties Effective January 1, 2016, pursuant to House Bill 1295 passed by the 84th Texas Legislature (Section 2252.908, Texas Government Code, as amended) and formal rules released by the Texas Ethics Commission (TEC), all contracts with private business entities requiring approval by the Scbertz City Council will require the on-line completion of Form 1295 "Certificate of Interested Parties." Form 1295 is also required for any and all contract amendments, extensions or renewals. Contractors are required to complete and file electronically with the Texas Ethics Commission using the online filing application. CITY OF SCHERTZ PAGE 9 Prime Controls, L.P. Service Agreement Please visit the State of Texas Ethics Commission website, https://www.ethics.state.tx.us/whatsnew/elf info forml295.htm and hlths://www.ethics.state.tx.us/tec/1295-Info.htm for more information. IF YOU HAVE ANY QUESTIONS ABOUT COMPLIANCE, PLEASE CONSULT YOUR OWN LEGAL COUNSEL. COMPLIANCE IS THE INDIVIDUAL RESPONSIBILITY OF EACH PERSON OR AGENT OF A PERSON WHO IS SUBJECT TO THE FILING REQUIREMENT. AN OFFENSE UNDER CHAPTER 176 IS A CLASS C MISDEMEANOR. [The remainder of this page is intentionally left blank.] CITY OF SCHERTZ PAGE 10 Prime Controls, L.P. Service Agreement EXECUTED on this the day of , 2023. CITY: CONTRACTOR: By: By: Name: Steve Williams Name: Title: City Manager Title: ADDRESS FOR NOTICE: CITY: City of Schertz Attn: City Manager 1400 Schertz Parkway Schertz, Texas 78154 CONTRACTOR: Prime Controls, L.P. 1725 Lakepointe Drive Lewisville, TX 75057 CITY OF SCHERTZ PAGE 11 Prime Controls, L.P. Service Agreement Exhibit "A" SCOPE OF WORK General The City of Schertz SCADA system requires troubleshooting, maintenance and repairs from time to time. Contractor shall demonstrate knowledge and experience of the legacy and modern SCADA software and hardware in use by the City. Contractor shall be able to install, program, troubleshoot and maintain these systems while providing a cost-effective delivery of high -quality services in a prompt and reliable manner. Because any work under this contract is an on -call contract service, exact project specifications are not available. Specific work requirements will be identified in each individual project as they are deemed necessary and approved by the City. Contractor shall furnish all labor, supervision, tools, equipment, materials, metering instruments, supplies, parts, transportation, mobilization, insurance, bonds, permits, incidentals, and quality control necessary to provide on -call SCADA services on an "as -needed basis. The Contractor shall systematically examine, troubleshoot, repair, retrofit, upgrade, replace worn parts or components of equipment with new or reconditioned parts or components and install new equipment. When completed, the equipment must be cleaned, aligned, adjusted, calibrated, balanced, lubricated and all other tasks required, then tested to verify the efficient and effective performance of the component. Contractors must be available to provide service twenty-four (24) hours a day, seven (7) days a week, 365-days a year, including holidays throughout the duration of the contract, and are to give "priority" to all City trade service requests. Response times for trade work will be answered within a 24-hour period. Contractor shall provide City with a schedule indicating the date and time personnel will be at a particular facility to perform work. This schedule must be provided PRIOR to arrival at any facility. Contractor shall diligently prosecute the work to completion within the time set forth for each individual project. The period of performance shall include allowance for mobilization, holidays, weekend days, normal inclement weather, and cleanup. When possible, respondent must ensure that the purchase, delivery and storage of materials and equipment are made without interference to City operations and personnel. Contractor shall take all necessary precautions to ensure that no damage shall result from operations to private or public property. All damages must be reported, repaired or replaced by respondent at no cost to the City. CITY OF SCHERTZ PAGE 12 Prime Controls, L.P. Service Agreement Contractor must at all times keep the site, including storage areas, free from accumulations of waste materials. Before completing the work, respondent must remove from the premises all rubbish, tools, scaffolding, equipment, and materials not the property of the City. Upon completing the work, Respondent must leave the site in a clean and orderly condition satisfactory to the City. Final cleanup is part of the project, and respondent is responsible for all construction refuse disposal containers and their removal from the site. Service will be performed at a variety of City locations, including, but not limited to, restricted areas. All unique requirements and or regulations for each location shall be strictly followed by the selected respondent and personnel, and subcontractor's and personnel. The City, at its sole discretion, may request a criminal background check on any personnel entering City property. Warrant• General Warranty. Respondent shall warrant that work performed conforms to the project specifications or PO requirements and is free of any defect in equipment, material, or workmanship performed by respondent or any of its subcontractors or suppliers at any tier. All work provided by respondent shall be warranted for a minimum period of 1 year from the date of final acceptance of the work. Performance Warranty. Work performed under the on -call services contract shall meet all applicable standards and codes. Respondent shall guarantee all work against any defects in workmanship, and shall satisfactorily correct, at no cost to the City, any such defect that may become apparent within a period of 1 year after completion of work. The warranty period shall commence upon date of acceptance by the City. Material Warranty. Materials provided shall be in current production, as offered to commercial trade, and shall be of quality material. USED, SHOPWORN, DEMONSTRATOR, PROTOTYPE, RECONDITIONED OR DISCONTINUED MATERIALS ARE NOT ACCEPTABLE, unless previously approved by the City. Materials shall be warranted against material defects and defects in workmanship for a period of not less than 1 year. The warranty period shall commence upon date of acceptance by the City. If the manufacturer's standard warranty period exceeds one year, then the warranty period hereunder shall be the length of the manufacturer's warranty. Respondent shall be ultimately responsible for the warranty. Respondent shall provide the City with all manufacturers' warranty documents upon completion of service prior to leaving the job site. CITY OF SCHERTZ PAGE 13 Prime Controls, L.P. Service Agreement Pricing for Services Contractors labor rates set forth herein shall remain fixed and firm for term of contract. Material cost shall be paid at cost for each project at time services are requested. ervice Description Unit of Rate in Dollars Measure $116.00 SERVICE CALL: ONSITE INSPECTION, Hr TROUBLESHOOTING OR REPAIRS MONDAY - FRIDAY 7:30AM - 5:OOPM SERVICE CALL: ONSITE PROGRAMMING Hr $156.00 MONDAY - FRIDAY 7:30AM - 5:OOPM EMERGENCY SERVICE CALL: WEEKENDS Hr $155.00 (Tech) AND AFTER HOURS $156.00 (Automation Specialist) EMERGENCY SERVICE CALL: HOLIDAYS Hr $209.00 (Tech) $281.00 (Automation Specialist) CITY OF SCHERTZ PAGE 14 Prime Controls, L.P. Service Agreement Exhibit "B" REQUIREMENTS FOR ALL INSURANCE DOCUMENTS The Contractor shall comply with each and every condition contained herein. The Contractor shall provide and maintain the minimum insurance coverage set forth below during the term of its agreement with the City. Any Subcontractor(s) hired by the Contractor shall maintain insurance coverage equal to that required of the Contractor. It is the responsibility of the Contractor to assure compliance with this provision. The City of Schertz accepts no responsibility arising from the conduct, or lack of conduct, of the Subcontractor. INSTRUCTIONS FOR COMPLETION OF INSURANCE DOCUMENT With reference to the foregoing insurance requirements, Contractor shall specifically endorse applicable insurance policies as follows: 1. The City of Schertz shall be named as an additional insured with respect to General Liability and Automobile Liability on a separate endorsement. 2. A waiver of subrogation in favor of The City of Schertz shall be contained in the Workers Compensation and all liability policies and must be provided on a separate endorsement. 3. All insurance policies shall be endorsed to the effect that The City of Schertz will receive at least thirty (30) days written notice prior to cancellation or non -renewal of the insurance. 4. All insurance policies, which name The City of Schertz as an additional insured, must be endorsed to read as primary and non-contributory coverage regardless of the application of other insurance. 5. Chapter 1811 of the Texas Insurance Code, Senate Bill 425 82(R) of 2011, states that the above endorsements cannot be on the certificate of insurance. Separate endorsements must be provided for each of the above. 6. All insurance policies shall be endorsed to require the insurer to immediately notify The City of Schertz of any material change in the insurance coverage. 7. All liability policies shall contain no cross liability exclusions or insured versus insured restrictions. 8. Required limits may be satisfied by any combination of primary and umbrella liability insurances. 9. Contractor may maintain reasonable and customary deductibles, subject to approval by The City of Schertz. 10. Insurance must be purchased from insurers having a minimum AmBest rating of B+. 11. All insurance must be written on forms filed with and approved by the Texas Department of Insurance. (ACORD 25 2010/05). Coverage must be written on an occurrence form. 12. Contractual Liability must be maintained covering the Contractors obligations contained in the contract. Certificates of Insurance shall be prepared and executed by the insurance company or its authorized agent and shall contain provisions representing and warranting all endorsements and insurance coverages according to requirements and instructions contained herein. 13. Upon request, Contractor shall furnish The City of Schertz with certified copies of all insurance policies. 14. A valid certificate of insurance verifying each of the coverages required above shall be issued directly to the City of Schertz within ten (10) business days after contract award and prior to starting any work by the successful Contractor's insurance agent of record or insurance company. Also, prior to the start of any work and at the same time that the Certificate of Insurance is issued and sent to the City of Schertz, all required endorsements identified in sections A, B, C and D, above shall be sent to the City of Schertz. The certificate of insurance and endorsements shall be sent to: City of Schertz emailed to: purchasinV.64 schertz.com Purchasing Department Faxed to: 210-619-1169 1400 Schertz Parkway Schertz, TX 78154 CITY OF SCHERTZ PAGE 15 Prime Controls, L.P. Service Agreement .� CERTIFICATE TE OF LIABILITY INSURANCE 0"' oJ<,>•larcvoivrYrY, - _ �' 4lNiliQb+N 71118 0E 1171FICAVI iD IMEo AS A MATUIll OP iNFOilkiORM -ONLY AND CONFF.111P NO RIQIIT8 UNOH TIM CTInNiFICATit UOLDER, MM orfall.10ATR DOE'S HOT AiTMIA71VULY OR 11C0J4 MILY Ab UM% EMMIDqg ALTER MIT OOVERAUE AFFORDMO DY 'Rlu V01-10 E8 i1EL04N, Ti118 Ci!FtTihtCATB sir 011A RAN013 bOE4 NOT CONSTITUTE A CONTRACT OFTWOEN 7NII Met oto 199unult(B), AUTROHMM 1l'EN15MIMIIV1 0''Ft 00UOOR, A1`1D71aBCER71FICAT_LriIDLIDEM IM#II1Tl1f1Nfi Illhecot00aalolt4rorisai1ADOITIONRL111MKO,IliaPilCy(1PsjmuLl.h®mdunk*[R i1011BR0{I,4'f10 19WAIVirr},mu6I�JOGIlo1114 tatnllt anti s4n41111olte flf Iha POPI&A oorlllln Iallcl4g rolry r0011M tin slNllptMA111, A ilblanl9�li blI I311e crtllifeals Lion not aotrfor 0DIAs dip His C8111Narta Ita1r1_olrin l5au al�auoh tndoraoman�(s). 1'tu7 CIA Tw A19CIrraurnrwbllDal►rY j •—_—�••. __ _�—. (I DI 1<s:- - Tarfl",FL83353-OW � _ 1111 rUIR1etNDIMOVOMA" I Ivor uisvnrAA, Imuronr>DCtinUt ODM INAUREa xvie nrnplry !Irayxutbllrarufarwi�arr}or �� - ¢g E ' f 123 AplX9 Sueal iKsgAruorlltrursncoitrrdQr W Q40D0 ��� fiarnlla, iI.22x27•fl40i3 nrsuAfner 11rsurrvrlaoC�nNor --- ¢pgy�1 l+.1 it drnuroaiyocprlioi _ _ DDOM _ 0GVERAGUS CPi44 CVTR ku'M131:11: REVISION "UlmIM TIt18 igg TO cfliYtFY =T TI IE Mr1IFA 4P lNSUi M0C; It8TFD- oI LOW jlAV0 u[tN ISSUC 3 TO xNO u1sURED �A AED .AHO . FOR YMI iADUOY IVIVOO, I oldT�Yto. Ht97YITT1NMT";wMNo ANY RtdUiRerictiT, TA:Ri1 o1l COMixITION OF /d1Y CONTRACT 011 OY31ER DOMMENT WT11 A MMIr TOWWII TIM3 CEATIFICAT{r MY OE 1851,180 ORMY PORTM!PI. 711F NtSUFAIPOE ACFOT10 M BY Tfrt POLICIEft I -801090 Iir: EW iS 8Lr1 OT TO ALL 'Mr il'.t11AI5, 1(CLUSHINSM13CDrPO11100SOFFSucitPK)LICIELLE4AT_BSHOWN MAY HAVL BEEN I000EDAMID CLAWS. n Lrutrr 1 !I)ur[PAtP3ltafulY ,�-�- �_ � _ � � fFAr�loccurtnEnlje - i j G CncIN[REJu.OlHlrl4TLIKra1r7Y Y / ,; i tJ t nArD} - ryr llt9 �11Q.. CLAW* Wa ff) CCGIw .. rV[q l zr µrrusr,kia l� J GM ! AbiNilllKPW bit41119DD rpetouuawuwJyrrr, s1gQr3 rl- 0Wf014"#LEUAaIUjY r ZrrGE[ AGOREW ELL4AAPPLrEePE11: PJax4xre•t7bAWPAoo xIrona.011irrr'FJLl.'T.-T X farvAVIO .1 gOotLYetJ4sY¢4rFi+rsrr(i F 0 ItvT�9 1lLvrfb i2$i¢97-04 OiA7111L'L+ OI(I}i/ii)9PrLYnIM1Y1PK+cdMM f MAMAWOOS Iwros �~ �a+ ; X uMEMLLALrha X r7raCWi Y - F CrrooEUsuttWCs e IDMIN1111.4s I r� Cwus�l�ailE3ATE e YdtNiKEJUaQQNPEhIEATL4k h � —— j�. 1 •�it �Gl+s 1� iUIYft1FX1E1b7PAF11NEAlJrr0MjYG FI• FACIT RACCMs (whMu aJernWtWMI)i if NJA Y 4iR 1 C11birIbG0 81A?1(IDCO _ - - IiQ9Sk --•-_ Iltfrydllyr "MMrl E L as64sE.rwwrsprE+ a �O,gA.Q.., Yr�t,aEueea r ___ uE6t`nui;rne ¢.Lr12AA?1rX1t Lb F4 PISF iFr.P011GY'tIwo f MWO . L Durklaes Itlsk "4' --�^_ � i' %'" Pr�jl' i23To tllftplflUUD 011N11 M iMSIr URMOValun, lol1recsmonimat Uihalr biosalonalSor Sakes — 61,t�D0,9{IOaOrI{rolplJ�i.D�b.UOdfi C Rip UE�+CNPTNttBPFtPERA7r01ta1L9�1KTIaNDfYHiI�L4e(Ait{ihI.C1f14b1ariMiAlrandlS�ml!k4ft1+1#vt>',M_tMr�rt+i4sii�t�rdf GtIutlA+o danusry i• 7.0 i? moat t+o �ri11llon! VAUI Clsohlar i61 i, �$�I .III4 Gone �.$I3d23 ennEled 6Y 7oxoa f.cfllaletrXa 0�{i� 66RsMn 1n 281 ij. OP CE1i�1,�4A7t:ijQL#)LIT ._.. -, _ iiAhIC1:1,41yTIt7l� _ „- _ 00ULU ANY O7 T►tg JAW0M D1161DIUDlib POLIA94 Olt 0A'NOUL1: D 11EPORe CRY& Schetiz T14F Ix IRWItotJ bAlk' 111Fns014, NOTIcr VMR. ill DPLM- RED IN t 14008chertz rorkemy ACCOlklAANCOWINN14491,44MDYPAOYIB)DN . 1' ScirOtiz, 1'x 78154 �--� AM- f'tarchasing 15ep1. JrientoaaeetxerrEerirrnlis<d .a--~ oS AU1031112E12810ALATURE REQUIRED 11CRli _ iD SOBB-201 D ACORD CORPORATION, All rl®hte tooemod. A00RD 20 (20106) Tlm ACORD name and logo ore ro3}letorod wokle 4f ACORD CITY OF SCHERTZ PAGE 16 Prime Controls, L.P. Service Agreement (Instructions for completing and submitting a certificate to the City of Schertz) Complete the certificate of insurance with the information listed below: A) Certificate of Insurance date B) Producer (Insurance Agency) Information — complete name, address, telephone infonnation, & email address. C) Insured's (Insurance Policy Holder) Information — complete name & address information D) Insurer (name/names of insurance company) **(Remember the city requires all insurance companies to be Authorized to do business in the State of Texas be rated by A.M. Best with a rating of B+ (or better) Class VI (or higher) or otherwise be acceptable to the City if not rated by A.M. Best) E) NAIC 4 (National Association of Insurance Commissioners, a # that is assigned by the State to all insurance companies) F) Insurer letter represents which insurance company provides which type of coverage from D G) General Liability Insurance Policy — must have an (x) in box. Also, "Occurrence" type policy — must have an (x) in the box (occurrence policy preferred but claims made policy can be accepted with special approval) H) This section shall be filled in with "Y" for yes under Additional Insured for all coverages, except for Contractor Liability and Workers' Compensation. There shall also be a "Y" for yes under all coverages for subrogation waived. I) Automobile Liability Insurance — must be checked for Any Auto, All Owned Autos, Hired Autos J) Umbrella Coverage — must be checked in this section and by occurrence whenever it is required by written contract and in accordance with the contract value. K) Worker's Compensation and Employers Liability Insurance — information must be completed in this section of the certificate of insurance form (if applicable). L) Builder's Risk Policy — for construction projects as designated by the City of Schertz. Professional Liability Coverage — for professional services if required by the City of Schertz. M) Insurance Policy #'s N) Insurance policy effective dates (always check for current dates) O) Insurance Policy limits (See Insurance Requirements Checklist) P) This section is to list projects, dates of projects, or location of project. Endorsements to the insurance policy(ies) must be provided separately and not in this section. The following endorsements are required by the City of Schertz. (1) Adding the City of Schertz as an additional insured. The "additional insured" endorsement is not required for professional liability and workers compensation insurance; and (2) Waiver of Subrogation (3) Primary and Nan -Contributory (4) Cancellation Notice Q) City of Schertz's name and address information must be listed in this section R) Notice of cancellation, non -renewal, or material change to the insurance policy(ies) must be provided to the City of Schertz in accordance with a cancellation notice endorsement to the policy and/or per the policy provisions based on the endorsement adding the city as an additional insured. (Sec. 1811,155, Tex. Ins. Code) S) The certificate must be signed by the Authorized Agent in this section of the certificate form. CITY OF SCHERTZ PAGE 17 Prime Controls, L.P. Service Agreement Exhibit "C" EVIDENCE OF INSURANCE CITY OF SCHERTZ PAGE IS Prime Controls, L.P. Service Agreement